Bids Data Sheet (BDS)

The following specific data for the procurement of Goods to be procured shall complement, supplement, or amend the provisions in the Instructions to Bidders (ITB).  Whenever there is a conflict, the provisions herein shall prevail over those in ITB.

BDS Clause Number
ITB Number

Amendments of, and Supplements to, Clauses in the Instruction to Bidders

A. Introduction

BDS Clause Number 1
ITB Number 1.1

Name of Procuring Agency: Flood Forecasting Division (Pakistan Meteorological Department)

The subject of procurement is: Repair/Replacement of Machinery and IT equipment at FFD Lahore

Expected commencement date: Sunday, June 7, 2026

BDS Clause Number 2
ITB Number 2.1

Financial year for the operations of the Procuring Agency: 2025-26

Name and identification number of the Contract: P32597 

BDS Clause Number 3
ITB Number 4.6

JV/Consortium or Association Allowed: No
Number of JV/Consortium Members: Nil

B. Bidding Documents

BDS Clause Number 4
ITB Number 7.1

The Bidders may seek clarifications through EPADS v2.0: Clarification Date: Monday, May 18, 2026

BDS Clause Number 5
ITB Number 8.1

Any addendum, in case issued, shall be published on Flood Forecasting Division (Pakistan Meteorological Department) website  and on EPADS v2.0.

BDS Clause Number 6
ITB Number 9.1

List of documents required along with the bid:

1. Technical Specifications of the items to be provided.

BDS Clause Number 7
ITB Number 11.1

The qualification criteria to establish the supply / production capability of the bidder.

see Eligibility Criteria

BDS Clause Number 8
ITB Number 7.6
Services and Their related documents:
See section Required Services and Scope of Work

BDS Clause Number 9
ITB Number 13.1 & 13.2

Price schedule will be provided according to the format defined and acquired.
see section price schedule.

BDS Clause Number 10
ITB Number 7.6.2

 Specifications:

see section of specifications.

C. Preparation of Bids

BDS Clause Number 11
ITB Number 13.5

The price shall be Fixed.

BDS Clause Number 12
ITB Number 15.1

Currency of the Bids shall be : PKR

BDS Clause Number 13
ITB Number 16.1

The Bids/Bid Validity period shall be: 60 Days

BDS Clause Number 14
ITB Number 17.1

The amount of Bid Security shall be as defined in Bid Security Section for items and lots given in BDS 6
The Bid Security shall be in the form of: Pay Order, Banker's Cheque, Call at Deposit  

BDS Clause Number 15
ITB Number 17.3

The Bids security shall be valid for twenty-eight (28) days beyond the expiry of the Bids validity period specified in the bidding documents,  for example the bid validity is 180 days so the bid security shall be valid for  180+28 = 208 days.

BDS Clause Number 16
ITB Number 18.1

Alternative Bids to the requirements of the bidding documents will not be permitted.

D. Submission of Bids

BDS Clause Number 17
ITB Number 21.1

Bid shall be submitted online on EPADS v2.0 whereas hard copy of the bid security should be submitted to the following;

46-Jail Road, Lahore, Lahore City, Lahore (District), Lahore Division (Division), Punjab (Province).

Bids that are not submitted on EPADS v2.0 shall be disqualified.

The deadline for Bids submission is: Monday, June 1, 2026 08:00 AM

E. Opening and Evaluation of Bids

BDS Clause Number 18
ITB Number 26.1

The Bids opening shall take place on EPADS v2.0.

Day : Monday

Date: Monday, June 1, 2026

Time : 08:30 AM

BDS Clause Number 19
ITB Number 32.1

Selection technique adopted will be: Least Cost Based Selection (LCBS)
see Evaluation Criteria

F. Award of Contract

BDS Clause Number 20
ITB Number 49.1

The Performance guarantee shall: 10.00%.

The Performance Guarantee shall be acceptable in the form of: Pay Order, Banker's Cheque, Call at Deposit

21.

51.1

Arbitrator shall be appointed by mutual consent of the both parties.

G. Review of Procurement Decisions

BDS Clause Number 22
ITB Number 53.1

Grievence against this procurement shall be submitted online on EPADS v2.0.

A. General

1. Definitions
   1. Unless the context otherwise requires, the following terms whenever used in this Contract shall have the same meaning and shall be interpreted as  indicated
      1. “Applicable Law” means the laws and any other instruments having the force of law in the Government’s Country, or in such other country as may be specified in the Special Conditions of the Contract (SC), as they may be issued and in force from time to time;
      2. “The Contract” means an agreement enforceable by law;
      3. “The Contract Price” means the price payable to the Contractor under the Contract for the full and proper performance of its contractual obligations;
      4. “The Services” means the work to be performed by the Contractor pursuant to this Contract and as prescribed in the Specifications and Schedule of Activities included in the Contractor’s Bid;
      5. “Ancillary Services” means those services ancillary to the provision of Services, such as transportation and insurance, and any other incidental services, such as installation, commissioning, provision of technical assistance, training, and other such obligations of the Contractor covered under the Contract;
      6. “GCC” means the General Conditions of Contract contained in this section;
      7. “SCC” means the Special Conditions of Contract by which the GCC may be amended or supplemented;
      8. “Day” means calendar day unless indicated otherwise;
      9. “Effective Date” means the date on which this Contract comes into force and effect;
      10. “The  Contractor” means the individual or corporate body whose Bids to provide the Services has been accepted by the Procuring Agency;
      11. “The Project Site,” where applicable, means the place or places named in Bid Data Sheet and technical Specifications;
      12. “Government” means the Government of Pakistan;
      13. “Local Currency” means the currency of Pakistan;
      14.  “In Writing” means communicated in written form with proof of receipt;
      15. “Completion Date” means the date of completion of the Services by the Contractor  as certified by the Procuring Agency;
      16. “Foreign Currency” means any currency other than the currency of the country of the Procuring Agency;
      17. “Party” means the Procuring Agency or the Contractor, as the case may be, and “Parties” means both of them;
      18.  "Service" means any object of procurement other than goods or works;
      19. “Subcontractor” means any entity to which the Bidder subcontracts any part of the Services.
2. Applicable Law
   1. The contract shall be governed and interpreted in accordance with the laws of Pakistan, unless otherwise specified in SCC.
3. Language
   1. The Contract as well as all correspondence and documents relating to the Contract exchanged between the Contractorand the Procuring Agency, shall be written in the English language unless otherwise stated in the SCC.  Supporting documents and printed literature that are part of the Contract may be in another language provided these are accompanied by an accurate translation of the relevant passages in English, in which case, for purposes of interpretation of the Contract, this translation shall govern.
4. Notices
   1. Any notice, request, or consent made pursuant to this Contract shall be in writing and shall be deemed to have been made when delivered in person to an authorized representative of the Party to whom the communication is addressed, or when sent by registered mail, telex, telegram, or facsimile to such Party at the address specified in the SCC.
5. Location
   1. The Services shall be performed at such locations as the Procuring Agency may approve and as specified in SCC.
6. Authorized Representatives / Authority of Member in charge
   1. Any action required or permitted to be taken, and any document required or permitted to be executed, under this Contract by the Procuring Agency or the Contractor may be taken or executed by the officials specified in the SCC.

B. Commencement, Completion, Modification, and Termination of Contract

1. Effectiveness of Contract
   1. This Contract shall come into effect on the date the Contract is signed by both parties and such other later date as may be stated in the SCC.
2. Commencement of Services
   1. The Contractor shall confirm availability of Key Experts and begin carrying out the Services not later than the number of days after the Effective Date specified in the SCC.
3. Program schedule
   1. Before commencement of the Services, the Contractor shall submit to the Procuring Agency for approval a Program showing the general methods, arrangements, order and timing for all activities. The Services shall be carried out in accordance with the approved Program as updated.
4. Starting Date/Expiration Date
   1. The Contractor shall start carrying out the Services Five (05) days after the date the Contract becomes effective, or at such other date as may be specified in the SCC.
   2. Unless terminated earlier pursuant to Clause GCC 14 hereof, this Contract shall expire at the end of such time period after the Effective Date as specified in the SCC.
5. Entire Agreement
   1. This Contract contains all covenants, stipulations and provisions agreed by the Parties.  No agent or representative of either Party has authority to make, and the Parties shall not be bound by or be liable for, any statement, representation, promise or agreement not set forth herein.
6. Modification
   1. Any modification or variation of the terms and conditions of this Contract, including any modification or variation of the scope of the Services, may only be made by written agreement between the Parties. However, each Party shall give due consideration to any modification(s) or variation(s) made by the other Party.
   2. In cases of any modification(s) or variation(s), the prior written consent of the Procuring Agency is required.
7. Force Majeure
   1. Definition
      For the purposes of this Contract, “Force Majeure” means an event which is beyond the reasonable control of a Contractor and which makes a Contractor’s performance of its obligations under the Contract impossible or so impractical as to be considered impossible under the circumstances.
   2. No Breach of Contract
      The failure of a Party to fulfill any of its obligations under the contract shall not be considered to be a breach of, or default under, this Contract in so far as such inability arises from an event of Force Majeure, provided that the Party affected by such an event (a) has taken all reasonable precautions, due care and reasonable alternative measures in order to carry out the terms and conditions of this Contract, and (b) has informed the other Party as soon as possible about the occurrence of such an event.
   3. Extension of Time
      Any period within which a Contractor shall, pursuant to this Contract, complete any action or task, shall be extended for a period equal to the time during which such Party was unable to perform such action as a result of Force Majeure.
   4. Payments
      During the period of their inability to perform the Services as a result of an event of Force Majeure, the Contractor shall be entitled to continue to be paid under the terms of this Contract, as well as to be reimbursed for additional costs reasonably and necessarily incurred by them during such period for the purposes of the Services and in reactivating the Service after the end of such period.
8. Termination
   1. By the Procuring Agency
      The Procuring Agency may terminate this Contract in case of the occurrence of any of the events specified in paragraphs (a) through (e) of this Clause. In such an occurrence the Procuring Agency shall give at least thirty (30) calendar days’ written notice of termination to the Contractor in case of the events referred to in (a) through (d); at least sixty (60) calendar days’ written notice in case of the event referred to in (e);
      1. If the Contractor fails to remedy a failure in the performance of its obligations hereunder, as specified in a notice of suspension;
      2. If the Contractor becomes (or, if the Contractor consists of more than one entity, if any of its members becomes) insolvent or bankrupt or enter into any agreements with their creditors for relief of debt or take advantage of any law for the benefit of debtors or go into liquidation or receivership whether compulsory or voluntary;
      3. If the Contractor fails to comply with any final decision reached as a result of arbitration proceedings;
      4. If, as the result of Force Majeure, the Contractor is unable to perform a material portion of the Services for a period of not less than sixty (60) calendar days;
      5. If the Procuring Agency, in its sole discretion and for any reason whatsoever, decides to terminate this Contract;
   2. By the Contractor
      The Contractor may terminate this Contract, by not less than thirty (30) calendar days’ written notice to the Procuring Agency, in case of the occurrence of any of the events specified in paragraphs (a) through (d) of this Clause.
      1. If the Procuring Agency fails to pay any money due to the Contractor pursuant to this Contract and not subject to dispute within forty-five (45) calendar days after receiving written notice from the Contractor that such payment is overdue;
      2. If, as the result of Force Majeure, the Contractor is unable to perform a material portion of the Services for a period of not less than sixty (60) calendar days;
      3. If the Procuring Agency fails to comply with any final decision reached as a result of arbitration;
      4. If the Procuring Agency is in material breach of its obligations pursuant to this Contract and has not remedied the same within forty-five (45) days (or such longer period as the Bidder may have subsequently approved in writing) following the receipt by the Procuring Agency of the Contractor’s notice specifying such breach.

C. Obligations of the Contractor

1. General
   1. Standard of Performance
      1. The Contractor shall perform the Services and carry out the Services with all due diligence, efficiency and economy, in accordance with generally accepted professional standards and practices, and shall observe sound management practices, and employ appropriate technology and safe and effective equipment, machinery, materials and methods. The Contractor shall always act, in respect of any matter relating to this Contract or to the Services, as a faithful adviser to the Procuring Agency, and shall at all times support and safeguard the Procuring Agency’s legitimate interests in any dealings with the third parties;
      2. The Contractor shall employ and provide such qualified and experienced Experts and Sub-Contractors as are required to carry out the Services.
   2. Law Applicable to Services
      The Contractor shall perform the Services in accordance with the Contract and in accordance with the Law of Pakistan and shall take all practicable steps to ensure that any of its Experts and Sub-Bidders, comply with the Applicable Law. 
2. Conflict of Interests
   1. Contractor Not to Benefit from Commissions and Discounts
      The remuneration of the Contractor shall constitute the Contractor’s sole remuneration in connection with this Contract or the Services, and the Contractor shall not accept for their own benefit any trade commission, discount, or similar payment in connection with activities pursuant to this Contract or to the Services or in the discharge of their obligations under the Contract, and the Contractor shall use their best efforts to ensure that the Personnel, any Subcontractors, and agents of either of them similarly shall not receive any such additional remuneration.
   2. Contractor and Affiliates Not to be Otherwise Interested in Project
      The Contractor agree that, during the term of this Contract and after its termination, the Contractor and its affiliates, as well as any Subcontractor and any of its affiliates, shall be disqualified from providing Services (other than the Services and any continuation thereof) for any project resulting from or closely related to the Services.
   3. Prohibition of Conflicting Activities
      Neither the Bidder nor its Subcontractors nor the Personnel shall engage, either directly or indirectly, in any of the following activities:
      1. during the term of this Contract, any business or professional activities in the Government’s country which would conflict with the activities assigned to them under this Contract;
      2. during the term of this Contract, neither the Contractor nor their Subcontractors shall hire public employees in active duty or on any type of leave, to perform any activity under this Contract;
      3. after the termination of this Contract, such other activities as may be specified in the SCC.
3. Insurance to be Taken Out by the Contractor
   1. The Contractor(a) shall take out and maintain, and shall cause any Subcontractors to take out and maintain, at its (or the Sub-contractors’, as the case may be) own cost but on terms and conditions approved by the Procuring Agency, insurance against the risks, and for the coverage, as shall be specified in the SCC; and (b) at the Procuring Agency’s request, shall provide evidence to the Procuring Agency showing that such insurance has been taken out and maintained and that the current premiums have been paid.
4. Contractor’s Actions Requiring Procuring Agency’s Prior Approval
   1. The Contractor shall obtain the Procuring Agency’s prior approval in writing before taking any of the following actions:
      1. appointing such members of the Personnel not provided by the Contractor;
      2. changing the Program of activities; and
      3. any other action that may be specified in the SCC.
5. Reporting Obligations
   1. The Contractor shall submit to the Procuring Agency the reports and documents in the numbers, and within the periods as prescribed by the Procuring Agency.
6. Liquidated Damages
   1. Payments of Liquidated Damages
      The Contractor shall pay liquidated damages to the Procuring Agency at the rate per day stated in the SCC for each day that the Completion Date is later than the Intended Completion Date.  The total amount of liquidated damages shall not exceed the amount defined in the SCC.  The Procuring Agency may deduct liquidated damages from payments due to the Contractor.  Payment of liquidated damages shall not affect the Contractor’s liabilities.
   2. Correction for Over-payment
      If the Intended Completion Date is extended after liquidated damages have been paid, the Procuring Agency shall correct any overpayment of liquidated damages by the Contractor by adjusting the next payment certificate.  The Contractor shall be paid interest on the overpayment, calculated from the date of payment to the date of repayment, at the rates specified in SCC.
   3. Lack of performance penalty
      If the Contractor has not corrected a Defect within the time specified in the Procuring Agency’s notice, a penalty for Lack of performance will be paid by the Contractor. The amount to be paid will be calculated as a percentage of the cost of having the Defect corrected, assessed as specified in the Contractor
7. Performance Guarantee
   1. Within the time stipulated in the acceptance letter from the Procuring Agency, the successful Bidder shall furnish the Performance Guarantee in shape and amount specified in SCC.
   2. The proceeds of the Performance Guarantee shall be payable to the Procuring agency as compensation for any loss resulting from the Supplier’s failure to complete its obligations under the Contract.
   3. The Performance Guarantee shall be denominated in the currency of the Contract, or in a freely convertible currency acceptable to the Procuring agency and shall be in the acceptable form as specified in SCC.
   4. The Performance Guarantee will be discharged by the Procuring agency and returned to the Supplier not later than thirty (30) days following the date of completion of the Supplier’s performance obligations under the Contract, including any warranty obligations, unless otherwise specified in SCC.
8. Sustainable Procurement
   1. The Contractor shall conform to the sustainable procurement contractual provisions, if and as specified in the SCC.

D. Contractor’s Personnel

1. Description of Personnel
   1. The titles, agreed job descriptions, minimum qualifications, and estimated periods of engagement in the carrying out of the Services of the Contractor’s Key Personnel.  The Key Personnel listed by title as well as by name are hereby approved by the Procuring Agency.
2. Removal and / or Replacement of Personnel
   1. Except as the Procuring Agency may otherwise agree, no changes shall be made in the Key Personnel.  If, for any reason beyond the reasonable control of the Contractor, it becomes necessary to replace any of the Key Personnel, the Contractor shall provide as a replacement a person of equivalent or better qualifications.
   2. If the Procuring Agency finds that any of the Personnel have (i) committed serious misconduct or have been charged with having committed a criminal action, or (ii) have reasonable cause to be dissatisfied with the performance of any of the Personnel, then the Contractor shall, at the Procuring Agency’s written request specifying the grounds thereof, provide as a replacement a person with qualifications and experience acceptable to the Procuring Agency.
   3. The Contractor shall have no claim for additional costs arising out of or incidental to any removal and/or replacement of Personnel.

E. Obligations of the Procuring Agency

1. Change in the Applicable Law
   1. If, after the date of this Contract, there is any change in the Applicable Law with respect to taxes and duties which increases or decreases the cost of the Services rendered by the Contractor, then the remuneration and reimbursable expenses otherwise payable to the Contractor under this Contract shall be increased or decreased accordingly by agreement between the Parties, and corresponding adjustments shall be made to the amounts referred in the SCC.
2. Services and Facilities
   1. The Procuring Agency shall make available to the Contractor and the Experts, for the purposes of the Services and free of any charge, the services, facilities and property described in the Terms of Reference, at the times and in the manner specified in the Terms of Reference.
   2. In case that such services, facilities and property shall not be made available to the Contractor, the Parties shall agree on (i) any time extension that it may be appropriate to grant to the Contractor for the performance of the Services, (ii) the manner in which the Contractor shall procure any such services, facilities and property from other sources, and (iii) the additional payments, if any, to be made to the Contractor as a result thereof.

F. Payments to the Contractor

1. Contract Price
   1. The price payable shall be in Pakistani Rupees unless otherwise specified in the SCC.
2. Terms and Conditions of Payment
   1. Payments will be made to the Contractor according to the payment schedule stated in the SCC and as per actual invoice submitted by the Contractor.
   2. Unless otherwise stated in the SCC, the advance payment shall be made against the provision by the Contractor of a bank guarantee for the same amount, and shall be valid for the period stated in the SCC.  Any other payment shall be made after the conditions listed in the SCC for such payment have been met, and the Contractor have submitted an invoice to the Procuring Agency specifying the amount due.
3. Quality Control Identifying Defects
   1. The principle and modalities of Inspection of the Services by the Procuring Agency shall be as indicated in the SCC. The Procuring Agency shall check the Contractor’s performance and notify him of any Defects that are found.  Such checking shall not affect the Contractor’s responsibilities.  The Procuring Agency may instruct the Contractor to search for a Defect and to uncover and test any service that the Procuring Agency considers may have a Defect. Defect Liability Period is as defined in the SCC.
4. Correction of Defects, and Lack of Performance Penalty
   1. The Procuring Agency shall give notice to the contractor of any Defects before the end of the Contract.  The Defects liability period shall be extended for as long as Defects remain to be corrected.
   2. Every time notice a Defect is given; the contractor shall correct the notified Defect within the length of time specified by the Procuring Agency’s notice.
   3. If the contractor has not corrected a Defect within the time specified in the Procuring Agency’s notice, the Procuring Agency will assess the cost of having the Defect corrected, the contractor will pay this amount, and a Penalty for Lack of Performance.
5. Settlement of Disputes Amicable Settlement
   1. The Parties shall use their best efforts to settle amicably all disputes arising out of or in connection with this Contract or its interpretation.
6. Dispute Settlement
   1. Arbitration
      If any dispute of any kind whatsoever shall arise between the procuring agency and the contractor in connection with or arising out of the Contract, including without prejudice to the generality of the foregoing, any question regarding its existence, validity or termination, or the execution of the contract, the parties shall seek to resolve any such dispute or difference by mutual consultation. If the parties fail to resolve such a dispute or difference even after negotiations or mediation, then the dispute shall be referred within fourteen (14) days in writing by either party to the Arbitrator, with a copy to the other party.
      Any dispute in respect of which a notice of intention to commence arbitration has been given, in accordance with GCC sub-clause 32.1, shall be finally settled by arbitration. Arbitration may be commenced prior to or after completion of the Contract. Arbitration proceedings shall be conducted in accordance with Arbitration Act 1940.
      Notwithstanding any reference to arbitration herein, the parties shall continue to perform their respective obligations under the Contract unless otherwise agreed. The Procuring Agency shall continue to pay the Contractor any undisputed amounts due under the Contract during the resolution of any dispute.

SECTION VIII. SPECIAL CONDITIONS OF CONTRACT

The following Special Conditions of Contract shall supplement the General Conditions of Contract. Whenever there is a conflict, the provisions herein shall prevail over those in the Conditions of Contract. The corresponding clause number of the GCC is indicated in parentheses.

Number of GC Clause

Amendments of, and Supplements to, Clauses in the General Conditions of Contract

Definitions

The Procuring Agency is: Flood Forecasting Division (Pakistan Meteorological Department), Electronic Engineer 46-Jail Road, Lahore, Lahore City, Lahore (District), Lahore Division (Division), Punjab (Province).

The Supplier is:

The title of the subject procurement is:Repair/Replacement of Machinery and IT equipment at FFD Lahore

Number of GC Clause 2

Applicable/Governing Law:

The Contract shall be interpreted in accordance with the laws of Islamic Republic of Pakistan

Number of GC Clause 3

Language:

The language of the Contract, all correspondence and communications to be given, and all other documentation to be prepared and supplied under the Contract shall be in English.

Number of GC Clause 4

Notices:

The addresses for the notices are:

Procuring Agency: 

Flood Forecasting Division (Pakistan Meteorological Department), Electronic Engineer
46-Jail Road, Lahore, Lahore City, Lahore (District), Lahore Division (Division), Punjab (Province).
+92-323-453-6527
procurement.ffdlhr@gmail.com

Contractor/ Bidder: 

 [Name, address and telephone number].

The Contractor/ Bidder’s Representative(s)

[Name, address, telephone number and e-mail address]

Number of GC Clause 6.1

The Authorized Representatives are:

For the Procuring Agency:

Flood Forecasting Division (Pakistan Meteorological Department), Electronic Engineer
46-Jail Road, Lahore, Lahore City, Lahore (District), Lahore Division (Division), Punjab (Province).
+92-323-453-6527
procurement.ffdlhr@gmail.com

For the Bidder:

Name: ………………………

Designation: ……………..

Address: ……………………………..

Number of GC Clause 7

Effectiveness of the contract

The Contractor/Bidder shall be effective within ….. days from the date of signature of the Contract by both parties

Number of GC Clause 8

Commencement of Contract:

The Contractor/ Bidder shall provide Non-Consultancy Services from the effective date of contract.

Number of GC Clause 10.2

Expiration of Contract:

The time period shall be ………………….

Number of GC Clause 14

Termination

In the event of termination of the contract due to any reason as already defined in the General Conditions of Contract, the Bidder shall be responsible for providing to the Authority the Goods till the time of alternate arrangements.

Number of GC Clause 16

Conflict of Interest:

The Procuring Agency reserves the right to determine on a case-by-case basis whether the Bidder should be disqualified from providing goods or services due to a conflict of a nature described in Clause GCC 17.

Number of GC Clause 20

Liquidated Damages

If the Bidder fails to provide services as required under the contract or in case of any data loss/data breach or any incident compromising the data security or other such failures related to any services, the Bidder shall pay to the Procuring Agency as Liquidated Damages at a rate of 1.00% to 1.00% of the Contract value, in accordance with the extent of performance failure & the cost of investigating such incidents as judged by the Authority.

Number of GC Clause 21

Performance Guarantee:

The amount of performance guarantee shall be 10.00% of the contract price in acceptable form of Pay Order, Banker's Cheque, Call at Deposit

Number of GC Clause 27

Currency of Payment:

All the payment to be released to the contractor/Bidder shall be in Pakistani Rupees.

Number of GC Clause 28

Payment terms:

Payment will be made to the Bidder against the procured Goods and services according to the actual invoice or running bills submitted by the Bidder against the services provided within the time given in the conditions of the contract.

Number of GC Clause 29

Identifying Defects:

The Authority reserves the right at any time to inspect the premises of the provider to inspect the goods and monitor the goods being provided.

Inspections & Tests Requirements

For conformance to specifications and performance parameters, through Prior to delivery inspection (Inspection Report by Procurement Committee / Inspection Team)

Delivery & Documents

Copies of the Supplier’s invoice showing Goods’ description, quantity, unit price, and total amount;

Number of GC Clause 31

Following is the guidance for Dispute Resolution

1. If any dispute of any kind whatsoever shall arise between the Authority and the Bidder in connection with or arising out of the Contract, including without prejudice to the generality of foregoing, any question regarding its existence, validity, termination and the execution of the Contract – whether during developing phase or after their completion and whether before or after the termination, abandonment or breach of the Contract – the parties shall seek to resolve any such dispute or difference by mutual diligent negotiations in good faith within 14 (fourteen) days following a notice sent by one Party to the other Party in this regard.
2. At future of negotiation the dispute shall be resolved through mediation and mediator shall be appointed with the mutual consent of the both parties.
3. At the event of failure of mediation to resolve the dispute relating to this contract such dispute shall finally be resolved through binding Arbitration by sole arbitrator in accordance with Arbitration Act 1940. The arbitrator shall be appointed by mutual consent of the both parties. The Arbitration shall take place in Islamabad, Pakistan and proceedings will be conducted in English language. 
4. The cost of the mediation and arbitration shall be shared by the parties in equal proportion however the both parties shall bear their own costs and lawyer’s fees regarding their own participation in the mediation and arbitration. However, the Arbitrator may make an award of costs upon the conclusion of the arbitration making any party to the dispute liable to pay the costs of another party to the dispute.
5. Arbitration proceedings as mentioned in the above clause regarding resolution of disputes may be commenced prior to, during or after completion of the contract.

Notwithstanding any reference to the arbitration herein, the parties shall continue to perform their respective obligations under the Contract unless they otherwise agree that the Authority shall pay the Bidder any monies due to the Bidder.

Arbitrator’s fee:

The fee shall be specified in Pak Rupees, as determined by the Arbitrator, which shall be shared equally by both parties.

Appointing Authority for Arbitrator:

By the Mutual Consent or in accordance with the provisions of Arbitration Act, 1940, in case the parties fail to reach a consensus on the name of sole arbitrator, any party may submit an application to the Chief Justice Islamabad High Court for appointment of sole arbitrator. The Chief Justice IHC may appoint a former judge of any High Court or Supreme Court as the sole arbitrator to resolve the dispute between the parties.

Rules of procedure for arbitration proceedings: 

Any dispute between the Authority and a Bidder who is a national of the Islamic Republic of Pakistan arising in connection with the present Contract shall be referred to adjudication or arbitration in accordance with the laws of the Islamic Republic of Pakistan including Arbitration Act 1940, however above provision shall prevail in referring the case to the Arbitrator.

Place of Arbitration and Award:

The arbitration shall be conducted in English language and place of arbitration shall be at Islamabad. The award of the arbitrator shall be final and shall be binding on the parties.

Form 9: Bid Securing Declaration

Date: [insert date (as day, month and year)]

Bid No.:P32597

To: Flood Forecasting Division (Pakistan Meteorological Department), Electronic Engineer 46-Jail Road, Lahore, Lahore City, Lahore (District), Lahore Division (Division), Punjab (Province).

We, the undersigned, declare that:

We understand that, according to your conditions, Bids must be supported by a Bid Securing Declaration.

We accept that we will be blacklisted and henceforth cross debarred  for participating in respective category of public procurement proceedings for a period of (not more than) six months, if fail to abide with a bid securing declaration, however without indulging in corrupt and fraudulent practices, if we are in breach of our obligation(s) under the Bid conditions, because we:

1. have  withdrawn  or  modified  our  Bid  during  the  period  of  Bid  Validity specified in the Form of Bid;
2. Disagreement to arithmetical correction made to the Bid price; or
3. having been notified of the acceptance of our Bid by the Procuring Agency during the period of Bid Validity, (i) failure to sign the contract if required by Procuring Agency to do so or (ii) fail or refuse to furnish the Performance Security or to comply with any other condition precedent to signing the contract specified in the Bidding Documents.

We understand this Bid Securing Declaration shall expire if we are not the successful

Bidder, upon the earlier of (i) our receipt of your notification to us of the name of the successful Bidder; or (ii) twenty-eight (28) days after the expiration of our Bid.

SECTION IX: CONTRACT FORMS

THIS AGREEMENT made the _____ day of __________ 20_____ between Flood Forecasting Division (Pakistan Meteorological Department), Electronic Engineer 46-Jail Road, Lahore, Lahore City, Lahore (District), Lahore Division (Division), Punjab (Province).

 (hereinafter called “the Procuring Agency”) of the one part and [name of Bidder] of [city and country of Bidder] (hereinafter called “the Bidder”) of the other part:

WHEREAS the Procuring Agency invited Bids for provision of goods, viz., Repair/Replacement of Machinery and IT equipment at FFD Lahore (P32597) and has accepted a Bids by the Bidder for the provision of Goods in the sum of [contract price in words and figures] (hereinafter called “the Contract Price”).

NOW THIS CONTRACT WITNESSETH AS FOLLOWS:

1.   In this Contract words and expressions shall have the same meanings as are respectively assigned to them in the Conditions of Contract referred to.

2.   The following documents shall be deemed to form and be read and construed as part of this Contract, In the event of any ambiguity or conflict between the Contract Documents listed below, the order of precedence shall be the order in which the Contract Documents are listed below:-

1. This form of Contract;
2. the Form of Bids and the Price Schedule submitted by the Bidder;
3. the Schedule of Requirements;
4. the Technical Specifications;
5. the Special Conditions of Contract;
6. the General Conditions of the Contract;
7. the Procuring Agency’s Letter of Acceptance; and
8. [add here: any other documents]

3.   In consideration of the payments to be made by the Procuring Agency to the Bidder as hereinafter mentioned, the Bidder hereby covenants with the Procuring Agency to provide the Goods related services and to remedy defects therein in conformity in all respects with the provisions of the Contract.

4.   The Procuring Agency hereby covenants to pay the Bidder in consideration of the provision of Goods and the remedying of defects therein, the Contract Price or such other sum as may become payable under the provisions of the contract at the times and in the manner prescribed by the contract.

IN WITNESS whereof the parties hereto have caused this Contract to be executed in accordance with their respective laws the day and year first above written.

Signed, sealed, delivered by __________________the ________________ (for the Procuring Agency)

Witness to the signatures of the Procuring Agency:

………………………………………………

Signed, sealed, delivered by __________________the ________________ (for the Procuring Agency)

Witness to the signatures of the Bidder: …………………………………………………

Integrity Pact

DECLARATION OF FEES, COMMISSION AND BROKERAGE ETC. PAYABLE BYTHE SUPPLIERS OF GOODS, SERVICES & WORKS IN  CONTRACTS WORTH RS.10.00 MILLION OR MORE

Contract                           Number:  Contract                               Value:  Contract Title:

Dated:

[Name of Supplier] hereby declares that it has not obtained or induced the procurement of any contract, right, interest, privilege or other obligation or benefit from Government of Pakistan or any administrative subdivision or agency thereof or any other entity owned or controlled by it (GoP) through any corrupt business practice.

Without limiting the generality of the foregoing [Name of Supplier] represents and warrants that it has fully declared the brokerage, commission, fee etc. paid  or payable to anyone and not given or agreed to give and shall not give or agree to give to anyone within or outside Pakistan either directly or indirectly through any natural or juridical person, including its affiliate, agent, associate, broker, consultant, director, promoter, shareholder, sponsor or subsidiary, any commission, gratification, bribe, finder's fee or kickback, whether described as consultations fee or otherwise, with the object of obtaining or inducing the procurement of a contract, right, interest, privilege or other obligation or benefit in whatsoever form from GoP, except that which has been expressly declared pursuant hereto.

[Name of Supplier] certifies that it has made and will make full disclosure of all agreements and arrangements with all persons in respect of or related to the transaction with GoP and has not taken any action or will not take any action to circumvent the above declaration, representative or warranty.

[Name of Supplier] accepts full responsibility and strict liability for making and false declaration, not making full disclosure, misrepresenting fact or taking any action likely to defeat the purpose of this declaration, representation and warranty. It agrees that any contract, right interest, privilege or other obligation or benefit obtained or procured as aforesaid shall, without prejudice to any other right and remedies available to GoP under any law, contract or other instrument, be voidable at the option of GoP.

Notwithstanding any rights and remedies exercised by GoP in this regard, [Name of Supplier] agrees to indemnify GoP for any loss or damage incurred by it on account of its corrupt business practices and further pay compensation to GoP in an amount equivalent to ten time the sum of any commission, gratification, bribe, finder's fee or kickback given by [Name of Supplier] as aforesaid for the purpose of obtaining or inducing the procurement of any contract, right, interest, privilege or other obligation or benefit in whatsoever form from GoP.

Performance Guarantee Form

To:     Flood Forecasting Division (Pakistan Meteorological Department), Electronic Engineer 46-Jail Road, Lahore, Lahore City, Lahore (District), Lahore Division (Division), Punjab (Province).

WHEREAS [name of Bidder] (hereinafter called “the Bidder”) has undertaken, in pursuance of Contract No.  [reference number of the contract] dated [insert date] for provision of Goods(hereinafter called “the Contract”).

AND WHEREAS it has been stipulated by you in the said Contract that the Bidder shall furnish you with a Bank Guarantee by a reputable bank for the sum specified therein as security for compliance with the Bidder’s performance obligations in accordance with the Contract.

AND WHEREAS we have agreed to give the Bidders guarantee:

THEREFORE, WE hereby affirm that we are Guarantors and responsible to you, on behalf of the Bidder, up to a total of [amount of the guarantee in words and figures], and we undertake to pay you, upon your first written demand declaring the Bidder to be in default under the Contract and without cavil or argument, any sum or sums within the limits of [amount of guar­antee] as aforesaid, without your needing to prove or to show grounds or reasons for your demand or the sum specified therein.

This guarantee is valid until the: [insert date]

Signature and seal of the Guarantors

_____________________________________________________________________

[name of bank or financial institution]

_____________________________________________________________________

[address]

_____________________________________________________________________

[date}

Instruction to bidders