Public Notification | e-Pak Acquisition and Disposal System (EPADS)

Standard Bidding Document

Download Document

Download Document Download SBD

📑 Procurement Notice (NIT)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Published on: Thursday, March 19, 2026

Ref# : P13409

PROCUREMENT NOTICE

PROCUREMENT OF NON-CONSULTANCY SERVICES

The Material Management (Lahore Electricity Supply Company (LESCO)) has reserved Funds for the procurement planned for FY 2025-26. The Material Management (Lahore Electricity Supply Company (LESCO)) intends to apply part of the proceeds of this Fund to cover eligible payments under the contract for the “TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )”
The Material Management (Lahore Electricity Supply Company (LESCO)) invites Bids through EPADS v2.0 from eligible Bidders registered on EPADS v2.0 for provision of Non-Consultancy Services.
Single Stage-One Envelope Procedure of Principal Method of Procurement (i.e. Open Competitive Bidding) will be used by adopting Least Cost Based Selection (LCBS)Technique for the subject procurement, in line with the Public Procurement Rules, 2004 and any Regulations, and Instructions issued by the Authority (from time to time).
All Bids must be accompanied by a Bid Security described in Bid Security Section in Bidding Document in the form of Pay Order, Banker's Cheque, Call at Deposit, Bank Guarantee or Bid Securing Declaration on the prescribed format described.
E-Bidding documents, containing detailed terms & conditions, specifications and requirements etc. are available on e-Pak Acquisition and Disposal System (EPADS) at https://vendors.epads.gov.pk/.
The e-bids, prepared in accordance with the instructions in the e-Bidding documents, must be submitted through EPADS v2.0 on or before Thursday, April 9, 2026 10:30 AM. E-bids will be opened on the same day at Thursday, April 9, 2026 11:00 AM. Manual submission of Bids shall not be entertained. Those vendors who have not yet registered on the new version of EPADS v2.0, may register themselves on https://vendors.epads.gov.pk/. A tutorial to explain the registration process is available at https://www.youtube.com/watch?v=MNW6T38v7tc

7. In terms of Rules 48 of Public Procurement Rules, 2004 Grievance Redressal Committee (GRC) is notified for the subject procurement and notification copy is available on the procuring agency’s website and also available on EPADS v2.0 as well as Authority’s website at (www.ppra.org.pk).

Material Management (Lahore Electricity Supply Company (LESCO)), Assistant Manager Procurement
LESCO Head Quarter, 22-A, Queens Road., Lahore City, Lahore (District), Lahore Division (Division), Punjab (Province).
+92-370-499-0342
ammm5@lesco.gov.pk

📑 Instructions to Bidders (ITB)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Published on: Thursday, March 19, 2026

Ref# : P13409

A. Introduction

Scope of Bids
1. The Procuring Agency (PA), as indicated in the Bids Data Sheet (BDS) invites Bids through EPADS v2.0 for the provision of Non-Consultancy Services for as specified in the BDS and in Section Evaluation Criteria, Specifications & Schedule of Requirements. The name, identification, and number of items/deliverables are provided in the BDS. Single Stage-One Envelope procedure of the open competitive method shall be used. The successful Bidders will be expected to provide the services within the specified period and timeline(s) as stated in the BDS.
Source of Funds
1. Source of funds is referred in Clause-1 of Invitation for Bids.
Fraud & Corruption
1. As defined under Rule 2(1)(f) of the Public Procurement Rules, 2004.
Eligible Bidders
1. A bidder is eligible to participate in a procurement process if the bidder:
  1. possesses or has access to the technical competence, financial resources, equipment and other physical facilities, personnel, managerial capability, experience and reputation necessary to complete the procurement contract;
  2. has the legal capacity to enter into a procurement contract;
  3. is not insolvent, in receivership, bankrupt or being wound up and its activities or affairs are not suspended or being administered under any Act, by a court or by a judicial officer;
  4. is not the subject of legal proceedings for any of the matters mentioned in sub-rule (c);
  5. has fulfilled or has made substantial arrangements satisfactory to the relevant authorities, to fulfil its obligations to pay taxes and social security (where applicable) other contributions of its employees; and
  6. has not, or in the case of a company, its owners and beneficial owners, directors or officers have not, been convicted of a criminal offence related to:
    1. its professional conduct; or
    2. a bidder (or, in the case of a company, its key individuals such as owners, beneficial owners, directors, or officers) must not have engaged in any prohibited practice, such as fraud, corruption, collusion, or coercion, within the time period stated in the bidding documents, which can be up to three years before the start of the procurement process. Additionally, the bidder must not have been debarred (i.e., banned) from participating in public procurement processes in Pakistan or by any international organization or country. If they have, they are ineligible to participate in the current bidding.
2. The procuring agency may require a bidder participating in the procurement process to provide the prescribed documentary evidence or other information to satisfy itself that the bidder is qualified in accordance with the criteria in sub-clause (1).
3. A procuring agency shall set out in the bidding document all the criteria for qualification to be applied in accordance with sub-clause (1).
4. Except as permitted under the Ordinance, Rules and Regulations, the procuring agency shall not establish a criterion for eligibility of a bidder that:
  1. discriminates against or among a bidder or against categories of bidders; or
  2. is not required for the performance of the procurement contract; or
  3. is not related to the avoidance or management of legal, reputational or economic risk to the procuring agency unless it is in the national interest to do so, and the criteria is set out in the bidding documents.
5. A procuring agency shall assess the eligibility of a bidder for participation in the procurement process against the criteria for qualification under sub-clause (1).
6. In the case of a joint venture, consortium, or association, all members shall be jointly and severely liable for the execution of the contract in accordance with the terms and conditions of the contract. The joint venture, consortium, or association shall nominate a lead member as nominated in the BDS,
7. who shall have the Authority to conduct all business for and on behalf of any and all the members of Joint venture, consortium, or association during the bidding process, and in case of award of contract, during the execution of the contract.
8. The appointment of the lead Member in the joint venture, consortium, or association shall be confirmed by submission of valid power of Attorney to the procuring agency.
9. Subject to the limits specified in the BDS, the procuring agency may allow bidders to participate in the form of a Joint Venture (JV). However, each party in the JV must individually meet the eligibility criteria specified in the BDS
10. No Bidder can be a sub-contractor while submitting a Bids individually or as a member of a joint venture in the same Bidding process.
Qualification of the Bidder
1. All Bidders shall provide in Section VI, Bid Forms, a preliminary description of the proposed work method and schedule, including drawings and charts, as necessary.

B. Bidding Documents

Contents of Standard Bidding Document
1. The Services required, bidding procedure, and terms and conditions of the contract are prescribed in the bidding document. In addition to the Invitation for Bids, the bidding document which should be read in conjunction with any addendum issued in accordance with ITB 6.1 include:
  
  Section I -Invitation to Bid
  Section II Instructions to Bidders (ITB)
  Section III Bid Data Sheet (BDS)
  Section IV Eligible Countries
  Section V Evaluation Criteria, Specifications, Schedule of Requirements, and Technical Specifications.
  Section VI Bidding Forms
  Section VII Fraud & Corruption
  Section VIII – Material & Non-material deviation
  Section IX General Conditions of Contract (GCC)
  Section X Special Conditions of Contract (SCC)
  Section XI Contract Forms
2. The Bidder is expected to examine all instructions, requirements, forms, terms and specifications in the bidding documents. Failure to furnish all the information required in the bidding document will be at the Service provider’s risk and may result in the rejection of his bids.
Clarifications
1. Clarifications of the bidding documents may be requested in writing through EPADS v2.0 by any bidder up to three days prior to the deadline for the submission of bids.
  
  The procuring agency shall respond promptly and in writing to any request by a bidder for clarification of the bidding documents and, in any event, no later than two days prior to the deadline for the submission of bids or proposals.
  
  Responses to requests for clarification shall be communicated simultaneously and in writing to all bidders participating in the procurement proceedings.
  
  No bidder shall be allowed to alter or modify his bid after the bids have been opened however, the procuring agency may seek and accept clarification to the bid that do not change the substance of the bid, through EPADS v2.0.
2. Procuring Agency's response will be uploaded on the EPADS v2.0, including a description of the inquiry.
3. Should the Procuring Agency deem it necessary to amend the bidding document as a result of a clarification, it shall do so following the procedure under ITB 8 .
4. If indicated in the BDS, the bidder’s designated representative is invited at the bidder’s cost to attend a pre-bid meeting at the place, date and time mentioned in the BDS. During this pre-bid meeting, prospective bidder(s) may request clarification(s) regarding the schedule of requirements, the Evaluation Criteria or any other aspects of the bidding document.
5. Minutes of the pre-bid meeting, if applicable, including the text of the questions asked by bidders, and the responses given, together with any responses prepared after the meeting will be uploaded on EPADS v2.0. Any modification to the bidding document that may become necessary as a result of the pre-bid meeting shall be made by the Procuring Agency exclusively through the use of an Addendum pursuant to ITB 8 .
6. To assist in the examination, evaluation and comparison of Bids of the Bidders, the Procuring Agency may, ask any Bidder for a clarification of its bid including breakdown of prices, through EPADS v2.0. Any clarification submitted by a bidder that is not in response to a request by the Procuring Agency shall not be considered.
  No change in the prices or substance of the bid shall be sought, offered, or permitted.
  The alteration or modification in the bid which in any way affect the following parameters will be considered as a change in the substance of a bid:
  1. evaluation & qualification criteria;
  2. required scope of work or specifications;
  3. all securities requirements;
  4. tax requirements;
  5. terms and conditions of bidding documents; and
  6. change in the ranking of the bidders.
    From the time of bid(s) opening to the time of contract award, if any bidder wishes to contact the procuring agency on any matter related to the bid, it should do so in writing or through electronic form that provides record of the content of communication.
Amendment of Bidding documents
1. Before the deadline for submission of bids, the procuring agency for any reason, whether at its own initiative or in response to a clarification requested by a prospective bidder or pre-bid meeting may modify the bidding documents by issuing addendum.
2. Any addendum issued including the notice of any extension of the deadline shall be part of the bidding document pursuant to ITB 8 .1 shall be uploaded on EPADS v2.0 as well as Authority’s website. The procuring agency shall promptly publish the addendum at the procuring agency’s website indicated in the BDS:
  
  Provided that the bidder who had either already submitted his bid, shall have the right to withdraw his already submitted bid and submit the revised bid, prior to the original or extended bid submission deadline.
3. To give prospective bidders reasonable time in which to take an addendum/corrigendum into account in preparing their bids, the Procuring Agency may, at its discretion, extend the deadline for the submission of bids:
  
  Provided that the Procuring Agency shall extend the deadline for submission of bids, if such an addendum is issued within last three (03) days of the bid submission deadline.

C. Preparation of Bids

Documents Constituting the Bids
1. The bids prepared by the bidders shall constitute the following components: -
  1. Forms of bid and Bid Prices completed in accordance with ITB 10 and 11;
  2. Documentary evidence established in accordance with ITB 8 that services to be provided by the bidder are eligible services, and conform to the bidding documents;
  3. Documentary evidence established in accordance with ITB 9 that the bidder is eligible and/or qualified for the subject bidding process;
  4. Documentary evidence established in accordance with ITB 9.3 that the bidder has been authorized to provide the services;
  5. Bid security or Bids Securing Declaration furnished in accordance with ITB 14; and
  6. Any other document required in the BDS.
Documents Establishing Eligibility of the Services and Conformity to bidding documents
1. To establish the conformity of the Non-Consulting Services to the Bidding document, the bidder shall furnish as part of its bid the documentary evidence that services provided conform to the requirements.
2. Standards for the provision of the Non-Consulting Services are intended to be descriptive only and not restrictive.
Documents Establishing Eligibility and Qualification of the Bidder
1. Pursuant to ITB 8, the bidder shall furnish, as part of itsbid, all those documents establishing the bidder’s eligibility to participate in the bidding process and/or its qualification to perform the contract if its bid is accepted.
2. The documentary evidence of the bidder’s eligibility to bids shall establish to the satisfaction of the procuring agency that the bidder, at the time of submission of its bid, is from an eligible country as defined in Section-IV titled as “Eligible Countries”.
3. The documentary evidence of the bidder’s qualifications to perform the contract if its bid is accepted shall establish to the satisfaction of procuring agency that:
  1. the bidder has the financial, technical, and supply/production capability necessary to perform the Contract, meets the qualification criteria specified in BDS.
  2. that the bidder meets the qualification criteria listed in the Bids Data Sheet.
Form of Bid
1. The bidder shall fill the Form of Bid furnished in the bidding documents. The Bid Forms must be completed without any alterations to its format and no substitute shall be accepted.
Bids Prices
1. The Bids Prices quoted by the bidder in the Forms of Bid and in the price schedule shall conform to the requirements specified or exclusively mentioned hereafter in the bidding document.
2. All items in the Schedule of Requirements must be listed and priced separately in the Price Schedules. If a Price Schedule shows items listed but not priced and neither explicitly mentioned, their prices shall be construed to be included in the prices of other items.
3. The Bid price to be quoted in the Forms of Bid in accordance with ITB 12 shall be the total price of the bid, excluding any discounts offered.
4. The bidder shall indicate on the appropriate Price Schedule, the unit prices (where applicable) and total bid price of the services, it proposes to provide under the contract.
5. Prices quoted by the bidder shall be fixed during the currency of the contract and not subject to variation on any account. A bid submitted with an adjustable price will be treated as non-responsive and shall be rejected pursuant to ITB 28, unless otherwise price adjustment is permissible under Conditions of the Contract. (May be reviewed)
Price Adjustment
1. Price adjustment shall not be applicable on the contract with less then 12 months period.
2. Procuring agency may increase the remuneration of the human resources involved in non-consultancy services upto maximum 15% on annual basis.
3. Procuring agency shall incorporate the provisions to allow wage rate in compliance with Federal Government’s minimum wage notification, subject to the condition that clause 11.2 shall not be applicable in that case.
Bids Currencies
1. Prices shall be quoted in Pakistani Rupees unless otherwise specified in the BDS.
Bid Validity Period
1. Bid(s) shall remain valid for the period specified in the BDS after the bid submission deadline prescribed by the Procuring Agency. A Bid valid for a shorter period shall be rejected by the Procuring Agency as non-responsive. The period of bid validity will be determined from the complementary bid securing instrument i.e. the expiry period of bid security or bid securing declaration as the case may be.
Bid Security or Bid Securing Declaration
1. Unless otherwise specified in the BDS, the bidder shall furnish as part of its bid, in the amount and currency specified in the BDS or Bid Securing Declaration on the format provided in Section VI (Bid Forms) The scanned copy of the Bids Security shall be uploaded in the EPADS v2.0 while submitting bid, whereas the original forms of Bid Security shall be submitted to the procuring agency before the bid submission deadline. The bidder who failed to submit the original bid security before the submission deadline shall be disqualified straightaway.
2. The Bid Security or Bid Securing Declaration is required to protect the Procuring Agency against the risk of Bidder’s conduct which would warrant the security’s forfeiture, pursuant to ITB 17.5
3. The Bid Security shall be payable promptly upon written demand by the Procuring Agency in case any of the conditions listed in 14.5 are invoked.
4. Unsuccessful Bidders’ Bid Security will be discharged or returned as promptly as possible after the award of contract, however in no case later than thirty (30) days after the expiration of the period of Bid Validity prescribed by the Procuring Agency pursuant to ITB 13. The Procuring Agency shall make no claim to the amount of the Bid Security, and shall promptly return the Bid Security document, whichever of the following that occurs earliest:
  1. the expiry of the Bid Security;
  2. the entry into force of a procurement contract and the provision of a Performance Guarantee, for the performance of the contract if such a guarantee, is required by the bidding document;
  3. the rejection by the Procuring Agency of all Bids;
  4. the withdrawal of the Bid prior to the deadline for the submission of bids, unless the bidding document stipulate that no such withdrawal is permitted.
5. The Bid Security may be forfeited or the Bid Securing Declaration executed:
  1. if a bidder:
    1. withdraws its bid during the period of bid validity as specified by the Procuring Agency, and referred by the bidder in the Forms of Bid, except as provided for in the ITBs; or
    2. does not accept the correction of errors pursuant to ITB 26; or
  2. in the case of a successful bidder fails:
    1. to sign the contract in accordance with ITB 32; or
    2. to furnish Performance Guarantee in accordance with ITB 33.
6. The bid security shall be valid for a period specified in BDS. Bids with shorter bid security validity period shall be rejected straight away.
Alternative Bids by Bidders
1. Alternatives will not be considered, unless specifically allowed for in the BDS.
2. When alternative times for completion are explicitly invited, a statement to that effect will be included in the BDS and the method of evaluating different time schedules will be described in Evaluation and Qualification Criteria.
Withdrawal, Substitution, and Modification of Bids
1. Before Bids submission deadline, any bidder may withdraw, substitute, or modify his bid after it has been submitted.
Format and Signing of Bids
1. The bidder shall prepare and submit his bid with due diligence after carefully reading all the terms and conditions before submission through EPADS v2.0.
2. Any interlineations, erasures, or overwriting shall be valid only if they are signed by the person(s) signing the forms of bid.

D. Submission of Bids

Submission of Bids through EPADS v2.0 before Dead deadline
1. The Technical and Financial Bids as the case may be, shall be submitted in the due portion of the EPADS v2.0, before bid submission deadline. The bid submission option shall be automatically disabled once the deadline is over.
2. The Procuring Agency may, under exceptional circumstances and at its discretion, extend the deadline for the submission of bids by amending the Bidding Documents in accordance with ITB 8. In such a case, all rights and obligations of the Procuring Agency and the Bidders that were previously subject to the original deadline shall thereafter be subject to the revised deadline.

E. Opening and Evaluation of Bids

Opening & Evaluation of Bids by the Procurement Cell
1. As per Rule 10 of Public Procurement Rules, 2025
  (PA to establish a Procurement Cell which shall carryout procurements a per Rule 10 of Public Procurement Rules, 2025)
Opening & Evaluation of Bids by the Bid Evaluation Committee
1. As per Rule 11 of Public Procurement Rules, 2025
  (PA to constitute odd number Bid Evaluation Committee for the purpose of bid opening and evaluation of all procurements with an estimated value up to two billion rupees)
Third Party Validation
1. In compliance with Rule 12 of Public Procurement Rules, 2025, the third-party validation committee or firm shall validate all procurements above five hundred million and up to two 2 billion rupees. The third-party validation shall be conducted at specifications, bidding documents preparation, technical (if any) & final evaluation stages.
External Bid Evaluation Committee
1. As per Rule 13 of Public Procurement Rules, 2025, procurements with an estimated value above two billion rupees shall be opened and evaluated by the Procuring Agency’s notified External Bid Evaluation Committee.
Opening of Bids
1. The Procuring Agency will open all bids through EPADS, in the presence of bidders’ or their representatives who choose to attend, and other parties with a legitimate interest in the bid proceedings at the place, on the date and at the time, specified in the BDS. The Bidders’ representatives present shall sign attendance sheet as proof of their attendance.
2. The bids shall be opened one at a time, and the following read out and recorded: (a) the name of the bidder; (c) the presence of a bid security, if required; and (d) any other details as the procuring agency may consider appropriate.
3. No bid will be rejected at the time of bid opening except for bids whose bid security has not been provided to the procuring agency before submission deadline.
4. The procuring agency shall prepare minutes of the bid opening. The record of the bid opening shall include, as a minimum: the name of the bidder and the bid price, if applicable.
Confidentiality
1. Information relating to the examination, clarification, evaluation and comparison of bids and recommendation of contract award shall not be disclosed to bidders or any other person(s) not officially concerned with such process, until the time of the announcement of the respective evaluation report.
2. Any effort by a bidder to influence the procuring agency processing of bids or award decision may result in the rejection of his bid.
Preliminary Examination of Bids
1. Prior to the detailed evaluation of bids, the procuring agency will determine whether each bid:
  1. meets the eligibility criteria defined in ITB 3;
  2. has been prepared as per the format and contents defined by the procuring agency in the bidding document;
  3. is accompanied by the required securities; and
  4. is substantially responsive to the requirements of the bidding document.
2. The procuring agency will confirm that the documents and information specified under ITB 9,10 and 11 have been provided in the bids. If any of these documents or information is missing, or is not provided in accordance with the Instructions to Bidders, the bids shall be rejected.
3. If a bid is not substantially responsive, it will be rejected by the procuring agency and may not subsequently be evaluated for complete technical responsiveness.
Examination of Terms and Conditions, Technical Evaluation
1. The procuring agency shall evaluate the technical aspects of the bids submitted in accordance with ITB 21, to confirm that all requirements specified in Evaluation Criteria, Technical Specifications and Schedule of Requirements,prescribed inthe bidding document have been met without material deviation or reservation.
2. If after the examination of the terms and conditions and the technical evaluation, the procuring agency determines that the bid is not substantially responsive in accordance with ITB 21, it shall reject the bids.
Correction of Errors
1. Bids determined to be substantially responsive will be checked for any arithmetic errors. Errors will be corrected as follows: -
  1. if there is a discrepancy between unit prices and the total price that is obtained by multiplying the unit price and quantity, the unit price shall prevail, and the total price shall be corrected, unless in the opinion of the procuring agency there is an obvious misplacement of the decimal point in the unit price, in which the total price as quoted shall govern and the unit price shall be corrected;
  2. if there is an error in a total corresponding to the addition or subtraction of sub-totals, the sub-totals shall prevail and the total shall be corrected; and
  3. where there is a discrepancy between the amounts in figures and in words, the amount in words will govern.
  4. Where there is discrepancy between grand total of price schedule and amount mentioned on the Forms of bid, the amount referred in Price Schedule shall be treated as correct subject to elimination of other errors.
2. The amount stated in the bid will be adjusted by the procuring agency in accordance with the above procedure for the correction of errors and, with the concurrence of the bidder that shall be considered as binding upon the bidder. If the Bidder does not accept the corrected amount, his bid will then be rejected, and the Bid Security may be forfeited or the Bid Securing Declaration may be executed in accordance with ITB 17.
Conversion to Single Currency
1. As per Rule 30(2) of Public Procurement Rules, 2004.
Evaluation of Bids
1. The procuring agency shall evaluate bids in accordance with Rule 30 of Public Procurement Rules, 2004 and compare only those bids determined to be substantially responsive, pursuant to ITB 24.
2. In evaluating the Technical Bids of each Bidder, the Procuring Agency shall apply the evaluation criteria and methodologies specified in the Bid Data Sheet (BDS) and in accordance with the Statement of Requirements and Technical Specifications. No other evaluation criteria or methodologies shall be permitted.
3. In case of tie of bids, the bidders shall be provided an opportunity to offer their best and final monetary offer through EPADS. However, in no case the rates shall be higher than the original financial bids.
4. The Procuring agency evaluation of a bid will take into account:
  1. the bid price, excluding provisional sums and the provision, if any, for contingencies in the summary bill of quantities, but including day work items, where priced competitively;
  2. price adjustment for correction of arithmetic errors in accordance with ITB 26;
5. converting the amount resulting from applying (a) and (b) above, if relevant, to a single currency in accordance with ITB 27;
6. The estimated effect of the price adjustment provisions of the Conditions of Contract, applied over the period of execution of the Contract, shall not be taken into account in bid evaluation.
7. If these bidding documents allow bidders to quote separate prices for different lots, and the award to a successful bidder of multiple lots, the methodology of evaluation to determine the lowest evaluated lot combinations in the Form of Bid, is specified in the BDS.
Determination of Most Advantageous Bids
1. Selection technique will be adopted for determining the Successful Bid in accordance with the criteria referred in the BDS or prescribed in the separate section titled as Evaluation Criteria.
Abnormally Low Financial Bids
1. Procuring agency may reject a bid if it has determined that the price, in combination with other constituent elements of the bid, is abnormally low in relation to the subject matter of the procurement, such that it raises material concerns on the part of the procuring agency, as to the ability of the bidder to perform the procurement contract satisfactorily for the offered price.
  A procuring agency shall not reject a bid as abnormally low under sub-clause (1) above unless the procuring agency –
  1. requested in writing through EPADS from the bidder a written clarification of his bid, including a detailed price analysis of his bid price in relation to the subject matter of the procurement contract, scope, methodology, schedule, allocation of risks and responsibilities and any other requirements of the bidding document; and
  2. having taken account, the information provided by the bidder in response to a request under paragraph (a) and the information included in the bid, the procuring agency determines that the bidder has failed to demonstrate its ability to perform the procurement contract satisfactorily for the offered price.
    
    The procuring agency shall promptly communicate to the bidder concerned its decision to reject the bid, including the reasons for the decision.
Rejection of Bids
1. As per Rule 33 of the Public Procurement Rules, 2004
Cancellation of procurement
1. As per Rule 46 of Public Procurement Rules, 2025
Single Responsive Bid
1. The procuring agency may consider single responsive subject to underlying conditions of Rule 38(b) of the Public Procurement Rules, 2004.
Alternate Dispute Resolution (ADR)
1. As per Rule 66 of Public Procurement Rules, 2025
Arbitration Clause
1. (Appointing Authority for the Arbitrator shall be Chief justice of Honorable Islamabad High Court OR Managing Director (PPRA) OR Secretary (Ministry of Law & Justice),
Fee of the Arbitrator
1. The fee shall be specified in PKR as detrmined by the Appointing Authority and shall be shared equally by each party.
Socio-economic development
1. As per Rule 63 of Public Procurement Rules, 2025, PA to encourage the inclusiveness of small and medium enterprises, and marginalized groups by according preferences in line with the notified policies of the Federal Government
Environmental objectives
1. As per Rule 64 of the Public Procurement Rules, 2004, The procuring agency may seek to procure services with a reduced environmental impact throughout their life cycle when compared to services with the same primary function that may otherwise be procured.

F. Award of Contract

Appointment of Contract Manager
1. The procuring agency shall designate a Contract Manager for each procurement or class of procurement who shall manage the contract as per Rule 58 & 59 of the Public Procurement Rules, 2004.
Criteria of Award
1. The procuring agency will award the Contract to the bidder whose bid has been determined to be substantially responsive to the bidding document and who has been declared as Successful Bid .
Procuring Agency’s Right to reject All Bids
1. The procuring agency reserves the right to reject all the Bids and to annul the procurement process at any time prior to acceptance of the bid(s), without thereby incurring any liability to the affected bidder(s).
2. Notice of the rejection of all bids shall be given promptly to all bidders that have submitted the bids. The procuring agency shall upon request communicate to any bidder the grounds for the rejection of his bid, but is not required to justify those grounds.
Procuring Agency’s Right to Vary Quantities at the Time of Award
1. The procuring agency reserves the right, at the time of contract award, to increase or decrease not more than 15% of the original scope of related services originally specified in the Schedule of Requirements, provided that such variation does not exceed the percentage indicated in the Bid Data Sheet (BDS). This adjustment shall be made without any change in the unit price or other terms and conditions of the Bids and Bidding Documents.
Notification of Award
1. Prior to the award of contract, the procuring agency shall issue a Final Evaluation Report giving justification for acceptance or rejection of the bids.
2. Bidder whose bid has been accepted, will be notified for the award by the Procuring Agency prior to expiration of the Bid Validity period through EPADS. The Letter of Acceptance will state the sum that the procuring agency will pay the successful bidder in consideration for the execution of the scope of works as prescribed by the Contract (hereinafter and in the Contract called the "Contract Price).
3. The notification of award will constitute the formation of the Contract, subject to the condition that bidder furnish the Performance Guarantee and signing of the contract.
Signing of Contract
1. Promptly after notification of award, Procuring Agency shall send the successful bidder the draft agreement, incorporating all terms and conditions as agreed by the parties to the contract. The successful bidder and the procuring agency shall sign the contract.
Performance Guarantee
1. After the receipt of the Letter of Acceptance, the successful bidder, within the specified time, shall deliver to the Procuring Agency a Performance Guarantee in the amount and in the form stipulated in the BDS and SCC, denominated in the type and proportions of currencies in the Letter of Acceptance and in accordance with the Conditions of Contract.
2. Failure of the successful bidder to comply with the requirement of ITB 49.1 shall constitute sufficient grounds for the annulment of the award and forfeiture of the bid security, in which event the procuring agency may make the award to the next ranked bidder or call for new bids.
Advance Payment
1. The Procuring Agency will provide an Advance Payment as stipulated in the Conditions of Contract, subject to a maximum amount, as stated in the BDS. The Advance Payment request shall be accompanied by an Advance Payment Guarantee in the form provided in Contract Forms.
Arbitration
1. The Arbitrator shall be appointed by mutual consent of the both parties as per the provisions specified in the SCC.
Corrupt & Fraudulent Practices
1. Procuring Agencies (including beneficiaries of Government funded projects and procurement) as well as Bidders/Contractors under Government financed contracts, observe the highest standard of ethics during the procurement and execution of such contracts, and will avoid to engage in any corrupt and fraudulent practices.

G. Grievance Redressal & Complaint Review Mechanism

Constitution of Grievance Redressal
1. Procuring agency shall constitute a Grievance Redressal Committee (GRC) comprising of an odd number of persons with proper power and authorization to address the complaint. The GRC shall not have any of the members of Procurement Evaluation Committee. The committee must have one subject specialist depending the nature of the procurement.
GRC Procedure
1. Any aggrieved party or bidder as the case may be, may file grievance in accordance with Rule 48 of the Public Procurement Rules, 20 and Redressal of Grievance Regulations, 2022

H. Blacklisting/ Debarment

Procedure for Blacklisting/Debarment
1. The procuring agency may initiate blacklisting proceedings against contractor/supplier in accordance with Rule-19 of the Public Procurement Rules, 2004 , Mechanism for Blacklisting, Debarment Regulations, 2024 and “procedure for filling and disposal of review petition under rule-19(3) of the Public Procurement Rules, 2004.

📑 Bid Data Sheet (BDS)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Published on: Thursday, March 19, 2026

Ref# : P13409

Bids Data Sheet (BDS)

The following specific data for the procurement of Goods to be procured shall complement, supplement, or amend the provisions in the Instructions to Bidders (ITB). Whenever there is a conflict, the provisions herein shall prevail over those in ITB.

BDS Clause Number	ITB Number	Amendments of, and Supplements to, Clauses in the Instruction to Bidders
A. Introduction
1	1.1	Name of Procuring Agency: Material Management (Lahore Electricity Supply Company (LESCO)) The subject of procurement is: TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers ) Expected commencement date: Tuesday, June 30, 2026
2.	2.1	Financial year for the operations of the Procuring Agency: 2025-26 Name and identification number of the Contract: P13409
3.	4.6	JV/Consortium or Association Allowed: No Number of JV/Consortium Members: Nil
B. Bidding Documents
4.	7.1	The Bidders may seek clarifications through EPADS v2.0: Clarification Date: Tuesday, March 31, 2026
5.	8.1	Any addendum, in case issued, shall be published on Material Management (Lahore Electricity Supply Company (LESCO)) website and on EPADS v2.0.
6.	9.1	List of documents required along with the bid: Form of Bid and Bid Prices completed in accordance with Instructions. Documentary evidence established in accordance with Instructions that the Bidder is eligible and/or qualified for the subject bidding process. Documentary evidence established in accordance with instructions that the goods and related services to be supplied by the Bidder are eligible goods and services, and conform to the Bidding Documents. Bid security or Bid Securing Declaration furnished in accordance with Instructions Schedule of delivery Technical data and Literature in English giving out salient feature of the quoted item(s) along-with WAPDA/PEPCO standard specification. Bidders are required to submit details of all litigations, arbitration and other claims whether pending, threatened or resolved in last five years. The employer / Purchaser may disqualify bidder in the event that the total amount of pending or threatened litigations, arbitration and other claims represents twenty five percent (25%) of the Bidder’s net worth : Details in this regard should be submitted in the Bid on attached form of pending litigation (Alongwith proof / documentary evidences of required net worth) as per Annexure/Form Undertaking of non-blacklisting AND Non default certificate in any contract agreement/purchase order in WAPDA/NTDC/DISCOs Financial statements and documents to ascertain the financial health of bidder(In case of Litigation) Original bid security/bank security as per bidding document Schedule of prices in respect of equipment Integrity Pact (if applicable) Offer Letter/Form of Bid Annex-I of PPRA SRO 592 (Form-13) Forms available in the bidding document (Only Applicable Forms) Certificate that latest purchase procedure PPRA-2004 (amended to date) are acceptable to the bidder and are hereby agreed to by the bidder. Certificate that the material offered is in accordance with the NTDC Tender Specifications amended to date. Copy of Letter of Registration as General Order Supplier / Pre-qualification with NTDC/ DISCOs/PEPCO/WAPDA under relevant category of material. Copy of certificate of registration with Sales Tax Department along-with necessary undertaking that the name of your firm exists on active tax payer list of FBR. Valid ISO-18001/45001 Certification Valid Prototype approval from CE (S&S) NTDC, if applicable. Proforma showing performance of the firm in LESCO/DISCOS during last two fiscal / calendar years as per Pattern available in the bidding document (At least 02-Nos. P.Os and their relevant GRNs must be attached) Form-12
7.	11.1	The qualification criteria to establish the supply / production capability of the bidder. see Eligibility Criteria
8.	7.6	Services and Their related documents: See section Required Services and Scope of Work
9.	13.1 & 13.2	Price schedule will be provided according to the format defined and acquired. see section price schedule.
10.	7.6.2	Specifications: see section of specifications.
C. Preparation of Bids
11.	13.5	The price shall be Fixed.
12.	15.1	Currency of the Bids shall be : PKR
13.	16.1	The Bids/Bid Validity period shall be: 75 Days
14.	17.1	The amount of Bid Security shall be as defined in Bid Security Section for items and lots given in BDS 6 The Bid Security shall be in the form of: Pay Order, Banker's Cheque, Call at Deposit, Bank Guarantee
15.	17.3	The Bids security shall be valid for twenty-eight (28) days beyond the expiry of the Bids validity period specified in the bidding documents, for example the bid validity is 180 days so the bid security shall be valid for 180+28 = 208 days.
16.	18.1	Alternative Bids to the requirements of the bidding documents will not be permitted.
D. Submission of Bids
17.	21.1	Bid shall be submitted online on EPADS v2.0 whereas hard copy of the bid security should be submitted to the following; LESCO Head Quarter, 22-A, Queens Road., Lahore City, Lahore (District), Lahore Division (Division), Punjab (Province). Bids that are not submitted on EPADS v2.0 shall be disqualified. The deadline for Bids submission is: Thursday, April 9, 2026 10:30 AM
E. Opening and Evaluation of Bids
18.	26.1	The Bids opening shall take place on EPADS v2.0. Day : Thursday Date: *Thursday, April 9, 2026* Time : 11:00 AM
19.	32.1	Selection technique adopted will be: Least Cost Based Selection (LCBS) see Evaluation Criteria
F. Award of Contract
20.	49.1	The Performance guarantee shall: 5.00%. The Performance Guarantee shall be acceptable in the form of: Pay Order, Banker's Cheque, Call at Deposit, Bank Guarantee
21.	51.1	Arbitrator shall be appointed by mutual consent of the both parties.
G. Review of Procurement Decisions
22.	53.1	Grievence against this procurement shall be submitted online on EPADS v2.0.

Eligibility Criteria

Bidder's Type	Required Registration
Individual / Individual Consultant Sole Proprietorship Partnership Firm Company (Private Limited) Company (Public Limited) Company (Holding Company) Company (Limited by Guarantee) State Owned Enterprise (Private Limited) State Owned Enterprise (Public Limited)	FBR (NTN) FBR (GSTN)

Bidder's Type

Required Registration

Individual / Individual Consultant

Sole Proprietorship

Partnership Firm

Company (Private Limited)

Company (Public Limited)

Company (Holding Company)

Company (Limited by Guarantee)

State Owned Enterprise (Private Limited)

State Owned Enterprise (Public Limited)

FBR (NTN)

FBR (GSTN)

Eligibility Criteria	Document
i) The bidder must be prequalified and registered with LESCO / DISCO / any WAPDA formation under the relevant category of material being procured/repaired. ii) The bidder should have registered with Income Tax & Sales Tax Department iii) As per directions of FBR dated. 3.9.2015 conveyed vide C.E (Operation) PEPCO vide letter No. 1918-28 dated. 17. Note : Relevant Documents to be attached.	Yes
Bids are liable to be rejected and declared as rejected/non-responsive forthwith if:	No
1. The bidder does not submit the bid on E-PADs.2. Alternate proposal is submitted with the bid.3. The bid is submitted on other than the prescribed form or is incomplete or conditional.4. The bid is illegible in any material, part or contains alteration, additions, deletions, erasers other irregularities.	Yes
5. Not accompanied with a bid guarantee or with insufficient/less/short validity or un-acceptable tender/bid guarantee or on format other than provided in the bidding document or or not comply with ITB 18.1, 18.3 to 18.7 or amendment in bid guarantee or submitted bid guarantee is from Banks other than mentioned in bidding document.	Yes
6. Tender is in some way connected with bids submitted under namesdifferent from his own.7. Supply record (copies of contract) is not provided with the bid to ascertain the qualification criteria.	Yes
8. The offer is not accompanied with schedule of technical data &drawings of offered equipment and schedule of deviation (if any) duly filled in and un-signed. 9. Offer letter/Form of Bid as provided in the bidding document is not attached with the bid or not duly signed and stamped or filled by the bidder	Yes
10. Financial statements and documents are not attached with the bid as required in bidding document (in case of litigation)	Yes
11. Firm (Bidder/manufacturer/contractor etc.) blacklisted/debarred by any organization national/worldwide as per PPRA Rules, 2004 and any other instructions/clarifications imparted by PPRA regarding blacklisting/debarment of particular firm or any other firm.	Yes
12. Integrity Pact (If Applicable) is not attached with the bid.	Yes
13. Undertaking for Quality and Standards on the bidder sletter head stating that material being offered by the bidder shall comply to the WAPDA/NTDC/IEC amended to date standards and there will be no compromise on the quality of the product for what so ever reason is not attached with the bid	Yes
14. Bidder/manufacturer do not attach its registrations including FBR, pre-qualification/general order supplier etc	Yes
15. The bid covers only a part /portion of the required equipment / partial quantity instead of complete quantity mentioned in lot.	Yes
16. Any false statement made in the bid or conditional bid is submitted. 17. Any practice/act to influence the evaluation till award of the contract. 18. All the Applicable Forms which are mentioned in this bidding documents/Annexures are not filled and duly signed & stamped by the bidder.	Yes
19. The firm will be declared non-responsive if the firms /bidders/suppliers/contractors/local agents /subsidiaries, who have defaulted/did not supplied material/ poor performance /forfeiture of performance security / sub-standard material against any contract agreement/purchase order in WAPDA/NTDC/ DISCOs during the last two (02) years starting from the date of opening of this tender.	Yes
20. The firm/bidders/suppliers/contractors/local agents/subsidiaries will be declared non-responsive after accessing the net financial impact of loss suffered/borne due to litigation/non-delivery of material/retendering of the same material etc	Yes
The bidder shall submit an Undertaking along with his bid that the Bidder is not blacklisted/debarred by NTDC/WAPDA/DISCOs/any Government/Public department/Donor Agencies at the time of submission of bids. Non-submission of this undertaking may result in the rejection of the bid. The said undertaking will subsequently become part of Contract Agreement/purchase order as well.	Yes
22. Non-provision of information regarding beneficial owners on Form 13- Annex-I as per PPRA SRO 592 and in case, such owners / Beneficiary have other firms with different names registered as General Order Suppliers with DISCOs/ NTDC/ WAPDA or any procuring agency who are consistently non-performing (Non-delivery of material, non-submission of Performance Guarantees, Bid Guarantees, Advance Payments, non-execution of contract agreements etc.) then the bidder’s having same Beneficiary/ owners	Yes
23. All participating bidders quote the same price against offered material. Such activity shall be considered under fraudulent practice and action will be initiated as per rules. Moreover, matter will be forwarded to Competition Commission of Pakistan for further strict action.	Yes
Undertaking is not attached on letter head of the bidder that bidder complies with all the clauses, terms & conditions & literature of the entire bidding document and all attached requisite & supporting documents with the bid are genuine & authentic. Evaluator/ procuring agency has full leverage to determine the trueness of attached documents with the bid and if any document is found false/fake, then procuring agency may initiate action against the bidder as per provisions available in bidding d	Yes
25. Non-provision of Declaration on bidder’s letter head that bidder (in case bidder is also manufacturer) have not defaulted any contract agreement/purchase order in WAPDA/NTDC/DISCOs.	Yes
26. Non-submission of last three years income tax returns of FBR (In case of Litigation).	Yes
27. Any document found missing as per Form-2 (Documents / Certificates to be submitted with Bid) of the bidding documents.	No

Evaluation Criteria

Least Cost Based Selection (LCBS)

Required Services

Positions Without Lots :

Position	Delivery Schedule	Quantity	Bid Security
Reclamation of 200-KVA Repairable 200-KVA Repairable	Address: Dy. Manager, LESCO Regional Store Shalamar, Dy. Manager, LESCO Regional Store WalgonSohail, Dy. Manager, LESCO Regional Store Pattoki, Schedule: (i) 50% quantity will be repaired within 60-days and remaining 50% quantity shall be repaired in next 45-days starting from the date of issuance of work order. Early repair is also acceptable. Quantity: 60	60	400000
Reclamation of 200-KVA Irrepairable Distribution Transformers	Address: Dy. Manager, LESCO Regional Store Shalamar, Dy. Manager, LESCO Regional Store WalgonSohail, Dy. Manager, LESCO Regional Store Pattoki, Schedule: (i) 50% quantity will be repaired within 60-days and remaining 50% quantity shall be repaired in next 45-days starting from the date of issuance of work order. Early repair is also acceptable. Quantity: 40	40	250000

Related Services :

Services Specifications

Positions Without Lots :

Position: Reclamation of 200-KVA Repairable 200-KVA Repairable

Specifications / Requirements:

DDS-84:2007 with Amendment No.5 The material shall be supplied strictly according to NTDC’s standard specification and quantity mentioned in Form 3 & Form 4 1. The quoted prices on basis of free pick & drop at consignee’s Store Regional Store LESCO Shalamar Lahore, Walgon Sohail & Pattoki are firm & final on “AS IS WHERE IS BASIS” and shall not be escalated for any reason what so ever. The bidder can visit the Regional Stores of LESCO for visual checking of repairable Transformers before quoting per unit reclamation charges. 2. Repairable Transformers will be requisitioned through Chief Engineer (MM) LESCO. Chief Engineer (MM) LESCO will receive / dispatch inspected damaged transformers, specially loading and unloading will be provided by Dy. Manager, Regional Store LESCO Shalamar Lahore, Walgon Sohail & Pattoki. 3. The prices include the present duties, taxes and credits (copper, tubes & replaceable material etc). In case however the present duties and taxes are increased or new taxes/duties are imposed by the Govt. on finished goods, during the currency of the Contact, the same will be paid extra on production of documentary evidence. In case of decrease in duties/taxes by Govt. the prices will be decreased accordingly. 4. The prices are on FCS basis that includes the shifting of Repairable / Irrepairable transformers from Regional Store LESCO Shalamar Lahore, Walgon Sohail & Pattoki to the firms’ workshop and return reclaimed transformers from the firm’s workshop to Regional Store LESCO Shalamar Lahore, Walgon Sohail & Pattoki. 5. Inspection and Testing of reclaimed transformers will be carr5ied out in the premises of the firm for which necessary testing facilities will be provided and testing will be carried out in accordance with specification as described in Form 3 & Form 4, you shall bear the expenses for all those tests to be got carried out from outside authorized laboratories, if deemed necessary. 6. Transformer oil and enameled copper wire shall be got tested from RTL Faisalabad once in a year at the contractor expenses. 7. Deputy Manager, Regional Store LESCO Shalamar Lahore, Walgon Sohail & Pattoki will issue fresh GRN only after repairing Repairable / Irrepairable transformers of warranty period if any against the rate contract and to maintain up to date record as well as to avoid accumulation of Repairable / Irrepairable transformers with the firm. 8. The firm is directed to repair Repairable / Irrepairable on the “FIFO” basis. However, in exceptional cases the instructions can be issued by the Chief Engineer (M.M) for repair of specific capacity of transformers in accordance with requirement of field formations. 9. LESCO reserves the right to cancel the contract any time without assigning any reason in case if the Performance found not satisfactory. i- Newly installed tubes supported by ring having flat (MS Patti) strip ii- This work order/rate contract shall remain in force for a period “01-Year” from the date of its issuance. iii- The repair cost can be renewed after one year with mutual consent of both the parties to extend the contract for further one year or more, if desired.

Position: Reclamation of 200-KVA Irrepairable Distribution Transformers

Specifications / Requirements:

Scope of Work

The material shall be supplied strictly according to NTDC’s standard specification and quantity mentioned in Form 3 & Form 4

The quoted prices on basis of free pick & drop at consignee’s Store Regional Store LESCO Shalamar Lahore, Walgon Sohail & Pattoki are firm & final on “AS IS WHERE IS BASIS” and shall not be escalated for any reason what so ever. The bidder can visit the Regional Stores of LESCO for visual checking of repairable Transformers before quoting per unit reclamation charges.
Repairable Transformers will be requisitioned through Chief Engineer (MM) LESCO. Chief Engineer (MM) LESCO will receive / dispatch inspected damaged transformers, specially loading and unloading will be provided by Dy. Manager, Regional Store LESCO Shalamar Lahore, Walgon Sohail & Pattoki.
The prices include the present duties, taxes and credits (copper, tubes & replaceable material etc). In case however the present duties and taxes are increased or new taxes/duties are imposed by the Govt. on finished goods, during the currency of the Contact, the same will be paid extra on production of documentary evidence. In case of decrease in duties/taxes by Govt. the prices will be decreased accordingly.
The prices are on FCS basis that includes the shifting of Repairable / Irrepairable transformers from Regional Store LESCO Shalamar Lahore, Walgon Sohail & Pattoki to the firms’ workshop and return reclaimed transformers from the firm’s workshop to Regional Store LESCO Shalamar Lahore, Walgon Sohail & Pattoki.
Inspection and Testing of reclaimed transformers will be carr5ied out in the premises of the firm for which necessary testing facilities will be provided and testing will be carried out in accordance with specification as described in Form 3 & Form 4, you shall bear the expenses for all those tests to be got carried out from outside authorized laboratories, if deemed necessary.
Transformer oil and enameled copper wire shall be got tested from RTL Faisalabad once in a year at the contractor expenses.
Deputy Manager, Regional Store LESCO Shalamar Lahore, Walgon Sohail & Pattoki will issue fresh GRN only after repairing Repairable / Irrepairable transformers of warranty period if any against the rate contract and to maintain up to date record as well as to avoid accumulation of Repairable / Irrepairable transformers with the firm.
The firm is directed to repair Repairable / Irrepairable on the “FIFO” basis. However, in exceptional cases the instructions can be issued by the Chief Engineer (M.M) for repair of specific capacity of transformers in accordance with requirement of field formations.
LESCO reserves the right to cancel the contract any time without assigning any reason in case if the Performance found not satisfactory.

Newly installed tubes supported by ring having flat (MS Patti) strip
This work order/rate contract shall remain in force for a period “01-Year” from the date of its issuance.
The repair cost can be renewed after one year with mutual consent of both the parties to extend the contract for further one year or more, if desired.

Note:-

Bidder should submit 100% compliance undertaking of Technical Conditions / special provisions otherwise bid will be declared non-responsive.
Only one FCS rate should be quoted for supply of Stores at Regional Store Shalamar, Lahore, 132-KV Grid Station Walgon Sohail (Ferozewattwaan) and 132-KV Grid Station Pattoki. Percentage wise exact quantity will be allocated / distributed at the time of placing Letter of Intent (LOI) or award of contract.
The quoted FCS price in Pak Rupees shall be firm and final and not subject to escalation for any reason what-so-ever. The Tenderer shall be entirely responsible for all duties and Taxes and other such levies on finished goods/ components and raw material of the Contracted goods until delivery to the consignee(s). The Sales Tax be quoted separately.
This tender will be evaluated in the light of categorization policy formulated by WAPDA Authority and if any pre-qualified firm has not yet been categorized by WAPDA, it will be considered in category-1.
In case of any specific occurrence the shares will be distributed / allocated on the basis of previous performance in supplies against DISCOs Purchase Orders, manufacturing / repairing capacity / capability etc.
Conditional Bids / Rates will not be entertained / accepted.
Bid submission / Tender opening date & timings shall be observed strictly.
You have to submit the requisite Certificate dully filled in, regarding the Declaration of Fees, Commission & Brokerage etc. paid by you about Goods, Services & Works.
Cartel / pool rates are strictly prohibited. The firms found involved in collusive practice shall be dealt under PPRA Rules / PEPCO instructions.
In case of holiday announced by the Govt. of Pakistan, strike in LESCO or any other reasons what so ever due to which this office remains closed on the above scheduled tender opening date, the tender will be opened on next working day at same time and place / venue.
In case of new entrant, the tenderer should submit the copy of educational / regular purchase order issued by any DISCOs along-with its completion and performance of supplied material in the light of specification / instructions / guidelines issued by Chief Engineer (S&S) NTDC Lahore letter No.3187-97 dated. 20.10.2015, otherwise your firm will be considered for educational order / non-responsive.
The bidder’s Beneficiary Declaration certificate mentioning the names of beneficiary accounts as per PPRA SRO 592 and in case, such owners / Beneficiary have other firms with different names registered as General Order Suppliers with DISCO/ NTDC/WAPDA who are consistently non-performing (non-delivery of material, non-submission of performance Guarantees, Bid Guarantees, Advance Payments, non-execution of contract agreements etc.) then the bidder’s having same beneficiary / owners firm’s shall be declared as non-responsive. Copy of form of Beneficiary Declaration certificate is attached.
Marking of page number of the bid along with all enclosures must be ensured in sequence to ascertain the number of documents attached with the bidding documents, as per C.E (TS) Design memo No. 5686-91 dt.16.08.2024.
The word PEPCO shall be read and considered as "PPMC"

DELIVERY PERIOD:

50% quantity will be repaired within 60-days and remaining 50% quantity shall be repaired in next 45-days starting from the date of issuance of work order. Early repair is also acceptable.
The allocated quantity of Repairable / Irrepairable transformers shall be lifted and returned to Regional Store Shalamar LESCO Ltd. Lahore, Walgon Sohail & Pattoki duly repaired within a period of 45-days from the date of issuance of allocation / release order by the office of Chief Engineer (MM) LESCO.
Delivery period is the essence of the Contract and delivery must be completed not later than the dates specified. The terms “Delivery Date” shall mean the date of 1st day of Inspection or 15th day of Inspection Call whichever is earlier, shall be reckoned as date of delivery of Store to Consignee provided the goods accepted for supply have been delivered within 20-days of issue of Inspection Certificate subject to the condition that the supplier / manufacturer offers the material for Inspection at least 15-days prior to the due date and the offer is not rejected due to being a fake call or material not conforming to the specification.
FIFO rule will be strictly observed and applied in this contract.
Partial deliveries and partial payments are allowed.

CONSIGNEE

Dy. Manager, LESCO Regional Store Shalamar,

Dy. Manager, LESCO Regional Store WalgonSohail,

Dy. Manager, LESCO Regional Store

A) The inspection of reclaimed transformers will be carried out at contractor’s works jointly by the LESCO inspection committee or by one authorized representative of LESCO, if required by the competent authority. Notice in writing shall be given to the inspecting officers by the contractor when the store against the order is ready for inspection. All reasonable facilities as provided in the specification or followed by the industry or trade in general shall have to be afforded to the inspecting officers including their TA/DA by you at your expenses for carrying out inspection.

B) Following tests shall be carried out on reclaimed distribution transformers at the time of final inspection.

Visual Inspection
Measurement of No load losses
Measurement of load losses
measurement of percentage impedance M
Measurement of winding resistance
High Voltage Withstand Test
Induced voltage withstand test
Transformer Turn Ratio Test
Bird Protection Test
Transformer oil Test (see Note I)
Tank Pressure Test

Note 1: Following tests shall be carried out on Transformer oil.

i-Dielectric strength ii-Specific Gravity iii-Viscosity iv-Acidity v-Flash point vi-Pour Point

Note 2: Following shall be observed in visual inspection

i-Tank body ii-Tubes iii-Oil level indicator iv-Bushings v-Paint and any other physical defect / shortcoming.

m
Transformer Rating	IRON LOSS	COPPER LOSS	TOTAL LOSS
Wfe (Watts Ferrous)	Wcu (Watts Copper)	Wtot (Watts Total)
Specified / Max Watts	Specified / Max Watts	Specified / Max Watts
495 / 569	3410 / 3922	3905 / 4296

The reclaimed transformers shall be inspected according to the specification mentioned here-under for stage as well as final testing:-

Wapda Standard Specification No.DDS-84:2007 for distribution T/Fs with amendment

No.4 excluding all type tests.

WAPDA specification No.P-13-69 for Distribution Transformers excluding all types test.
WAPDA specification No.P-72-70 for Bushing Rod connectors etc.
IEC-296 for new transformer oil.
ASTMD1170-62 STMDE-107-79 (a) for various Neoprene Rubber & Cork gas kits.
BSS-3255-1955 press pan paper.
DIN-7733 PSP -3052 Press Board Sheet Press Board Block.
BSS-4516 part –IP 1969 for Enameled Copper Wire.
BSS-4653 Part-II 1970 for LT Paper Covered Copper Strip.
IEC-233-1974 for 11 KV Porcelain Bushing.
IEC-233-1974 for LT Porcelain Bushing.
Resin for transformer top cover for age long adherence and 8 KV di-electric with stand.
All HT and LT Bushing to be filled with epoxy resin.
All top covers nuts and bolts and lock plain washers shall be of reputable make, such as BMI Searose and Hescopak etc. All measures described under Annex-IV, V & VI shall be rigidly observed and followed.
Oil level indication glass shall be 100 % replaced.
Interior of transformer shall be painted with Red, Oxide of M/S Dulux, Berger or Buxly.
Exterior of Transformer shall be spray painted in Grey with enamel paint of M/s Dulux, Berger or Buxly, 4 tubes shall be orange painted in addition to “RECLAIMED KVA” in bold stencil in orange colour, on transformers body.
Reclaimed transformers shall be fitted with rating plate giving following information:-

Reclamation workshop name
Work Order No.
Date of repair
Transformer capacity, Transformer serial number the word "LESCO"

C) Inspection and Rejection:

The Inspecting Officer may reject a part or the whole of the consignment tendered for inspection, if after inspection such portion thereof as he may decide on his discretion he is satisfied that the consignment is below the requirements of the particulars governing the supply given in the work order.

The decision of the Inspecting Officer shall be binding on you.

If the stores are rejected as aforesaid, then without prejudice to the right of the purchaser. You may submit stores after re-repairing of those rejected but re-submission will not mean extension of delivery period.

On final rejection the consignee shall have the following rights:-

To get repaired the rejected goods at your cost and expense.
To terminate the contract and recover from you the loss to LESCO thereby

Price Schedule

For Individual Positions

#	Position Title	Quantity	Unit Price (PKR)	Total Price (PKR)	Delivery Location	Delivery Period / Year	Country of Origin
1
2

For Lots

#	Lot Title	Total Lot Price (PKR)	Country of Origin
1	[Lot 1 Title]

📑 General Conditions of Contract (GCC)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Published on: Thursday, March 19, 2026

Ref# : P13409

A. General

Definitions
1. Unless the context otherwise requires, the following terms whenever used in this Contract shall have the same meaning and shall be interpreted as indicated
  1. “Applicable Law” means the laws and any other instruments having the force of law in the Government’s Country, or in such other country as may be specified in the Special Conditions of the Contract (SC), as they may be issued and in force from time to time;
  2. “The Contract” means an agreement enforceable by law;
  3. “The Contract Price” means the price payable to the Contractor under the Contract for the full and proper performance of its contractual obligations;
  4. “The Services” means the work to be performed by the Contractor pursuant to this Contract and as prescribed in the Specifications and Schedule of Activities included in the Contractor’s Bid;
  5. “Ancillary Services” means those services ancillary to the provision of Services, such as transportation and insurance, and any other incidental services, such as installation, commissioning, provision of technical assistance, training, and other such obligations of the Contractor covered under the Contract;
  6. “GCC” means the General Conditions of Contract contained in this section;
  7. “SCC” means the Special Conditions of Contract by which the GCC may be amended or supplemented;
  8. “Day” means calendar day unless indicated otherwise;
  9. “Effective Date” means the date on which this Contract comes into force and effect;
  10. “The Contractor” means the individual or corporate body whose Bids to provide the Services has been accepted by the Procuring Agency;
  11. “The Project Site,” where applicable, means the place or places named in Bid Data Sheet and technical Specifications;
  12. “Government” means the Government of Pakistan;
  13. “Local Currency” means the currency of Pakistan;
  14. “In Writing” means communicated in written form with proof of receipt;
  15. “Completion Date” means the date of completion of the Services by the Contractor as certified by the Procuring Agency;
  16. “Foreign Currency” means any currency other than the currency of the country of the Procuring Agency;
  17. “Party” means the Procuring Agency or the Contractor, as the case may be, and “Parties” means both of them;
  18. "Service" means any object of procurement other than goods or works;
  19. “Subcontractor” means any entity to which the Bidder subcontracts any part of the Services.
Applicable Law
1. The contract shall be governed and interpreted in accordance with the laws of Pakistan, unless otherwise specified in SCC.
Language
1. The Contract as well as all correspondence and documents relating to the Contract exchanged between the Contractorand the Procuring Agency, shall be written in the English language unless otherwise stated in the SCC. Supporting documents and printed literature that are part of the Contract may be in another language provided these are accompanied by an accurate translation of the relevant passages in English, in which case, for purposes of interpretation of the Contract, this translation shall govern.
Notices
1. Any notice, request, or consent made pursuant to this Contract shall be in writing and shall be deemed to have been made when delivered in person to an authorized representative of the Party to whom the communication is addressed, or when sent by registered mail, telex, telegram, or facsimile to such Party at the address specified in the SCC.
Location
1. The Services shall be performed at such locations as the Procuring Agency may approve and as specified in SCC.
Authorized Representatives / Authority of Member in charge
1. Any action required or permitted to be taken, and any document required or permitted to be executed, under this Contract by the Procuring Agency or the Contractor may be taken or executed by the officials specified in the SCC.

B. Commencement, Completion, Modification, and Termination of Contract

Effectiveness of Contract
1. This Contract shall come into effect on the date the Contract is signed by both parties and such other later date as may be stated in the SCC.
Commencement of Services
1. The Contractor shall confirm availability of Key Experts and begin carrying out the Services not later than the number of days after the Effective Date specified in the SCC.
Program schedule
1. Before commencement of the Services, the Contractor shall submit to the Procuring Agency for approval a Program showing the general methods, arrangements, order and timing for all activities. The Services shall be carried out in accordance with the approved Program as updated.
Starting Date/Expiration Date
1. The Contractor shall start carrying out the Services Five (05) days after the date the Contract becomes effective, or at such other date as may be specified in the SCC.
2. Unless terminated earlier pursuant to Clause GCC 14 hereof, this Contract shall expire at the end of such time period after the Effective Date as specified in the SCC.
Entire Agreement
1. This Contract contains all covenants, stipulations and provisions agreed by the Parties. No agent or representative of either Party has authority to make, and the Parties shall not be bound by or be liable for, any statement, representation, promise or agreement not set forth herein.
Modification
1. Any modification or variation of the terms and conditions of this Contract, including any modification or variation of the scope of the Services, may only be made by written agreement between the Parties. However, each Party shall give due consideration to any modification(s) or variation(s) made by the other Party.
2. In cases of any modification(s) or variation(s), the prior written consent of the Procuring Agency is required.
Force Majeure
1. Definition
  For the purposes of this Contract, “Force Majeure” means an event which is beyond the reasonable control of a Contractor and which makes a Contractor’s performance of its obligations under the Contract impossible or so impractical as to be considered impossible under the circumstances.
2. No Breach of Contract
  The failure of a Party to fulfill any of its obligations under the contract shall not be considered to be a breach of, or default under, this Contract in so far as such inability arises from an event of Force Majeure, provided that the Party affected by such an event (a) has taken all reasonable precautions, due care and reasonable alternative measures in order to carry out the terms and conditions of this Contract, and (b) has informed the other Party as soon as possible about the occurrence of such an event.
3. Extension of Time
  Any period within which a Contractor shall, pursuant to this Contract, complete any action or task, shall be extended for a period equal to the time during which such Party was unable to perform such action as a result of Force Majeure.
4. Payments
  During the period of their inability to perform the Services as a result of an event of Force Majeure, the Contractor shall be entitled to continue to be paid under the terms of this Contract, as well as to be reimbursed for additional costs reasonably and necessarily incurred by them during such period for the purposes of the Services and in reactivating the Service after the end of such period.
Termination
1. By the Procuring Agency
  The Procuring Agency may terminate this Contract in case of the occurrence of any of the events specified in paragraphs (a) through (e) of this Clause. In such an occurrence the Procuring Agency shall give at least thirty (30) calendar days’ written notice of termination to the Contractor in case of the events referred to in (a) through (d); at least sixty (60) calendar days’ written notice in case of the event referred to in (e);
  1. If the Contractor fails to remedy a failure in the performance of its obligations hereunder, as specified in a notice of suspension;
  2. If the Contractor becomes (or, if the Contractor consists of more than one entity, if any of its members becomes) insolvent or bankrupt or enter into any agreements with their creditors for relief of debt or take advantage of any law for the benefit of debtors or go into liquidation or receivership whether compulsory or voluntary;
  3. If the Contractor fails to comply with any final decision reached as a result of arbitration proceedings;
  4. If, as the result of Force Majeure, the Contractor is unable to perform a material portion of the Services for a period of not less than sixty (60) calendar days;
  5. If the Procuring Agency, in its sole discretion and for any reason whatsoever, decides to terminate this Contract;
2. By the Contractor
  The Contractor may terminate this Contract, by not less than thirty (30) calendar days’ written notice to the Procuring Agency, in case of the occurrence of any of the events specified in paragraphs (a) through (d) of this Clause.
  1. If the Procuring Agency fails to pay any money due to the Contractor pursuant to this Contract and not subject to dispute within forty-five (45) calendar days after receiving written notice from the Contractor that such payment is overdue;
  2. If, as the result of Force Majeure, the Contractor is unable to perform a material portion of the Services for a period of not less than sixty (60) calendar days;
  3. If the Procuring Agency fails to comply with any final decision reached as a result of arbitration;
  4. If the Procuring Agency is in material breach of its obligations pursuant to this Contract and has not remedied the same within forty-five (45) days (or such longer period as the Bidder may have subsequently approved in writing) following the receipt by the Procuring Agency of the Contractor’s notice specifying such breach.

C. Obligations of the Contractor

General
1. Standard of Performance
  1. The Contractor shall perform the Services and carry out the Services with all due diligence, efficiency and economy, in accordance with generally accepted professional standards and practices, and shall observe sound management practices, and employ appropriate technology and safe and effective equipment, machinery, materials and methods. The Contractor shall always act, in respect of any matter relating to this Contract or to the Services, as a faithful adviser to the Procuring Agency, and shall at all times support and safeguard the Procuring Agency’s legitimate interests in any dealings with the third parties;
  2. The Contractor shall employ and provide such qualified and experienced Experts and Sub-Contractors as are required to carry out the Services.
2. Law Applicable to Services
  The Contractor shall perform the Services in accordance with the Contract and in accordance with the Law of Pakistan and shall take all practicable steps to ensure that any of its Experts and Sub-Bidders, comply with the Applicable Law.
Conflict of Interests
1. Contractor Not to Benefit from Commissions and Discounts
  The remuneration of the Contractor shall constitute the Contractor’s sole remuneration in connection with this Contract or the Services, and the Contractor shall not accept for their own benefit any trade commission, discount, or similar payment in connection with activities pursuant to this Contract or to the Services or in the discharge of their obligations under the Contract, and the Contractor shall use their best efforts to ensure that the Personnel, any Subcontractors, and agents of either of them similarly shall not receive any such additional remuneration.
2. Contractor and Affiliates Not to be Otherwise Interested in Project
  The Contractor agree that, during the term of this Contract and after its termination, the Contractor and its affiliates, as well as any Subcontractor and any of its affiliates, shall be disqualified from providing Services (other than the Services and any continuation thereof) for any project resulting from or closely related to the Services.
3. Prohibition of Conflicting Activities
  Neither the Bidder nor its Subcontractors nor the Personnel shall engage, either directly or indirectly, in any of the following activities:
  1. during the term of this Contract, any business or professional activities in the Government’s country which would conflict with the activities assigned to them under this Contract;
  2. during the term of this Contract, neither the Contractor nor their Subcontractors shall hire public employees in active duty or on any type of leave, to perform any activity under this Contract;
  3. after the termination of this Contract, such other activities as may be specified in the SCC.
Insurance to be Taken Out by the Contractor
1. The Contractor(a) shall take out and maintain, and shall cause any Subcontractors to take out and maintain, at its (or the Sub-contractors’, as the case may be) own cost but on terms and conditions approved by the Procuring Agency, insurance against the risks, and for the coverage, as shall be specified in the SCC; and (b) at the Procuring Agency’s request, shall provide evidence to the Procuring Agency showing that such insurance has been taken out and maintained and that the current premiums have been paid.
Contractor’s Actions Requiring Procuring Agency’s Prior Approval
1. The Contractor shall obtain the Procuring Agency’s prior approval in writing before taking any of the following actions:
  1. appointing such members of the Personnel not provided by the Contractor;
  2. changing the Program of activities; and
  3. any other action that may be specified in the SCC.
Reporting Obligations
1. The Contractor shall submit to the Procuring Agency the reports and documents in the numbers, and within the periods as prescribed by the Procuring Agency.
Liquidated Damages
1. Payments of Liquidated Damages
  The Contractor shall pay liquidated damages to the Procuring Agency at the rate per day stated in the SCC for each day that the Completion Date is later than the Intended Completion Date. The total amount of liquidated damages shall not exceed the amount defined in the SCC. The Procuring Agency may deduct liquidated damages from payments due to the Contractor. Payment of liquidated damages shall not affect the Contractor’s liabilities.
2. Correction for Over-payment
  If the Intended Completion Date is extended after liquidated damages have been paid, the Procuring Agency shall correct any overpayment of liquidated damages by the Contractor by adjusting the next payment certificate. The Contractor shall be paid interest on the overpayment, calculated from the date of payment to the date of repayment, at the rates specified in SCC.
3. Lack of performance penalty
  If the Contractor has not corrected a Defect within the time specified in the Procuring Agency’s notice, a penalty for Lack of performance will be paid by the Contractor. The amount to be paid will be calculated as a percentage of the cost of having the Defect corrected, assessed as specified in the Contractor
Performance Guarantee
1. Within the time stipulated in the acceptance letter from the Procuring Agency, the successful Bidder shall furnish the Performance Guarantee in shape and amount specified in SCC.
2. The proceeds of the Performance Guarantee shall be payable to the Procuring agency as compensation for any loss resulting from the Supplier’s failure to complete its obligations under the Contract.
3. The Performance Guarantee shall be denominated in the currency of the Contract, or in a freely convertible currency acceptable to the Procuring agency and shall be in the acceptable form as specified in SCC.
4. The Performance Guarantee will be discharged by the Procuring agency and returned to the Supplier not later than thirty (30) days following the date of completion of the Supplier’s performance obligations under the Contract, including any warranty obligations, unless otherwise specified in SCC.
Sustainable Procurement
1. The Contractor shall conform to the sustainable procurement contractual provisions, if and as specified in the SCC.

D. Contractor’s Personnel

Description of Personnel
1. The titles, agreed job descriptions, minimum qualifications, and estimated periods of engagement in the carrying out of the Services of the Contractor’s Key Personnel. The Key Personnel listed by title as well as by name are hereby approved by the Procuring Agency.
Removal and / or Replacement of Personnel
1. Except as the Procuring Agency may otherwise agree, no changes shall be made in the Key Personnel. If, for any reason beyond the reasonable control of the Contractor, it becomes necessary to replace any of the Key Personnel, the Contractor shall provide as a replacement a person of equivalent or better qualifications.
2. If the Procuring Agency finds that any of the Personnel have (i) committed serious misconduct or have been charged with having committed a criminal action, or (ii) have reasonable cause to be dissatisfied with the performance of any of the Personnel, then the Contractor shall, at the Procuring Agency’s written request specifying the grounds thereof, provide as a replacement a person with qualifications and experience acceptable to the Procuring Agency.
3. The Contractor shall have no claim for additional costs arising out of or incidental to any removal and/or replacement of Personnel.

E. Obligations of the Procuring Agency

Change in the Applicable Law
1. If, after the date of this Contract, there is any change in the Applicable Law with respect to taxes and duties which increases or decreases the cost of the Services rendered by the Contractor, then the remuneration and reimbursable expenses otherwise payable to the Contractor under this Contract shall be increased or decreased accordingly by agreement between the Parties, and corresponding adjustments shall be made to the amounts referred in the SCC.
Services and Facilities
1. The Procuring Agency shall make available to the Contractor and the Experts, for the purposes of the Services and free of any charge, the services, facilities and property described in the Terms of Reference, at the times and in the manner specified in the Terms of Reference.
2. In case that such services, facilities and property shall not be made available to the Contractor, the Parties shall agree on (i) any time extension that it may be appropriate to grant to the Contractor for the performance of the Services, (ii) the manner in which the Contractor shall procure any such services, facilities and property from other sources, and (iii) the additional payments, if any, to be made to the Contractor as a result thereof.

F. Payments to the Contractor

Contract Price
1. The price payable shall be in Pakistani Rupees unless otherwise specified in the SCC.
Terms and Conditions of Payment
1. Payments will be made to the Contractor according to the payment schedule stated in the SCC and as per actual invoice submitted by the Contractor.
2. Unless otherwise stated in the SCC, the advance payment shall be made against the provision by the Contractor of a bank guarantee for the same amount, and shall be valid for the period stated in the SCC. Any other payment shall be made after the conditions listed in the SCC for such payment have been met, and the Contractor have submitted an invoice to the Procuring Agency specifying the amount due.
Quality Control Identifying Defects
1. The principle and modalities of Inspection of the Services by the Procuring Agency shall be as indicated in the SCC. The Procuring Agency shall check the Contractor’s performance and notify him of any Defects that are found. Such checking shall not affect the Contractor’s responsibilities. The Procuring Agency may instruct the Contractor to search for a Defect and to uncover and test any service that the Procuring Agency considers may have a Defect. Defect Liability Period is as defined in the SCC.
Correction of Defects, and Lack of Performance Penalty
1. The Procuring Agency shall give notice to the contractor of any Defects before the end of the Contract. The Defects liability period shall be extended for as long as Defects remain to be corrected.
2. Every time notice a Defect is given; the contractor shall correct the notified Defect within the length of time specified by the Procuring Agency’s notice.
3. If the contractor has not corrected a Defect within the time specified in the Procuring Agency’s notice, the Procuring Agency will assess the cost of having the Defect corrected, the contractor will pay this amount, and a Penalty for Lack of Performance.
Settlement of Disputes Amicable Settlement
1. The Parties shall use their best efforts to settle amicably all disputes arising out of or in connection with this Contract or its interpretation.
Dispute Settlement
1. Arbitration
  If any dispute of any kind whatsoever shall arise between the procuring agency and the contractor in connection with or arising out of the Contract, including without prejudice to the generality of the foregoing, any question regarding its existence, validity or termination, or the execution of the contract, the parties shall seek to resolve any such dispute or difference by mutual consultation. If the parties fail to resolve such a dispute or difference even after negotiations or mediation, then the dispute shall be referred within fourteen (14) days in writing by either party to the Arbitrator, with a copy to the other party.
  Any dispute in respect of which a notice of intention to commence arbitration has been given, in accordance with GCC sub-clause 32.1, shall be finally settled by arbitration. Arbitration may be commenced prior to or after completion of the Contract. Arbitration proceedings shall be conducted in accordance with Arbitration Act 1940.
  Notwithstanding any reference to arbitration herein, the parties shall continue to perform their respective obligations under the Contract unless otherwise agreed. The Procuring Agency shall continue to pay the Contractor any undisputed amounts due under the Contract during the resolution of any dispute.

📑 Special Conditions of Contract (SCC)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Published on: Thursday, March 19, 2026

Ref# : P13409

SECTION VIII. SPECIAL CONDITIONS OF CONTRACT

The following Special Conditions of Contract shall supplement the General Conditions of Contract. Whenever there is a conflict, the provisions herein shall prevail over those in the Conditions of Contract. The corresponding clause number of the GCC is indicated in parentheses.

Number of GC Clause	Amendments of, and Supplements to, Clauses in the General Conditions of Contract
	Definitions The Procuring Agency is: Material Management (Lahore Electricity Supply Company (LESCO)), Assistant Manager Procurement LESCO Head Quarter, 22-A, Queens Road., Lahore City, Lahore (District), Lahore Division (Division), Punjab (Province). The Supplier is: The title of the subject procurement is:TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )
GCC 2	Applicable/Governing Law: The Contract shall be interpreted in accordance with the laws of Islamic Republic of Pakistan
GCC 3	Language: The language of the Contract, all correspondence and communications to be given, and all other documentation to be prepared and supplied under the Contract shall be in English.
GCC 4	Notices: The addresses for the notices are: Procuring Agency: Material Management (Lahore Electricity Supply Company (LESCO)), Assistant Manager Procurement LESCO Head Quarter, 22-A, Queens Road., Lahore City, Lahore (District), Lahore Division (Division), Punjab (Province). +92-370-499-0342 ammm5@lesco.gov.pk Contractor/ Bidder: [Name, address and telephone number]. The Contractor/ Bidder’s Representative(s) [Name, address, telephone number and e-mail address]
GCC 6.1	The Authorized Representatives are: For the Procuring Agency: Material Management (Lahore Electricity Supply Company (LESCO)), Assistant Manager Procurement LESCO Head Quarter, 22-A, Queens Road., Lahore City, Lahore (District), Lahore Division (Division), Punjab (Province). +92-370-499-0342 ammm5@lesco.gov.pk For the Bidder: Name: ……………………… Designation: …………….. Address: ……………………………..
GCC 7	Effectiveness of the contract The Contractor/Bidder shall be effective within ….. days from the date of signature of the Contract by both parties
GCC 8	Commencement of Contract: The Contractor/ Bidder shall provide Non-Consultancy Services from the effective date of contract.
GCC 10.2	Expiration of Contract: The time period shall be ………………….
GCC 14	Termination In the event of termination of the contract due to any reason as already defined in the General Conditions of Contract, the Bidder shall be responsible for providing to the Authority the Goods till the time of alternate arrangements.
GCC 16	Conflict of Interest: The Procuring Agency reserves the right to determine on a case-by-case basis whether the Bidder should be disqualified from providing goods or services due to a conflict of a nature described in Clause GCC 17.
GCC 20	Liquidated Damages If the Bidder fails to provide services as required under the contract or in case of any data loss/data breach or any incident compromising the data security or other such failures related to any services, the Bidder shall pay to the Procuring Agency as Liquidated Damages at a rate of 2.00% to 10.00% of the Contract value, in accordance with the extent of performance failure & the cost of investigating such incidents as judged by the Authority.
GCC 21	Performance Guarantee: The amount of performance guarantee shall be 5.00% of the contract price in acceptable form of Pay Order, Banker's Cheque, Call at Deposit, Bank Guarantee
GCC 27	Currency of Payment: All the payment to be released to the contractor/Bidder shall be in Pakistani Rupees.
GCC 28	Payment terms: Payment will be made to the Bidder against the procured Goods and services according to the actual invoice or running bills submitted by the Bidder against the services provided within the time given in the conditions of the contract.

GCC 29	Identifying Defects: The Authority reserves the right at any time to inspect the premises of the provider to inspect the goods and monitor the goods being provided. Inspections & Tests Requirements Inspection and Testing of reclaimed transformers will be carr5ied out in the premises of the firm for which necessary testing facilities will be provided and testing will be carried out in accordance with specification as described in Form 3 & Form 4, you shall bear the expenses for all those tests to be got carried out from outside authorized laboratories, if deemed necessary Transformer oil and enameled copper wire shall be got tested from RTL Faisalabad once in a year at the contractor expenses. (iii) Delivery period is the essence of the Contract and delivery must be completed not later than the dates specified. The terms “Delivery Date” shall mean the date of 1st day of Inspection or 15th day of Inspection Call whichever is earlier, shall be reckoned as date of delivery of Store to Consignee provided the goods accepted for supply have been delivered within 20-days of issue of Inspection Certificate : subject to the condition that the supplier / manufacturer offers the material for Inspection at least 15-days prior to the due date and the offer is not rejected due to being a fake call or material not conforming to the specification. (iv) FIFO rule will be strictly observed and applied in this contract. (v) Partial deliveries and partial payments are allowed. INSPECTION AND REJECTION i) The inspection officer may reject a part or the whole of the consignment tendered for inspection, if after inspection such portion thereof as he may decide on his direction, he is satisfied that the consignment is below the requirement of the particular governing the supply given in the NOA/Purchase order. ii) The decision of the inspecting officer shall be binding on you. iii) If the stores are rejected as aforesaid, then without prejudice to the right of the purchaser you may submit stores in replacement of those rejected but re-submission will not means extension of delivery period. iv) On final rejection the purchaser shall have the following rights (a) To purchase against the rejected goods at your cost and expense (b) To terminate the contract and recover the loss from you, the LESCO thereby incurs The inspection of reclaimed transformers will be carried out at contractor’s works jointly by the LESCO inspection committee or by one authorized representative of LESCO, if required by the competent authority. Notice in writing shall be given to the inspecting officers by the contractor when the store against the order is ready for inspection. All reasonable facilities as provided in the specification or followed by the industry or trade in general shall have to be afforded to the inspecting of Following tests shall be carried out on reclaimed distribution transformers at the time of final inspection. 1. Visual Inspection 2. Measurement of No load losses 3. Measurement of load losses 4. measurement of percentage impedance M 5. Measurement of winding resistance 6. High Voltage Withstand Test 7. Induced voltage withstand test 8. Transformer Turn Ratio Test 9. Bird Protection Test 10. Transformer oil Test (see Note I) 11. Tank Pressure Test Note 1: Following tests shall be carried out on Transformer oil. i-Dielectric strength ii-Specific Gravity iii-Viscosity iv-Acidity v-Flash point vi-Pour Point Note 2: Following shall be observed in visual inspection i-Tank body ii-Tubes iii-Oil level indicator iv-Bushings v-Paint and any other physical defect / shortcoming. Note 1: Following tests shall be carried out on Transformer oil. i-Dielectric strength ii-Specific Gravity iii-Viscosity iv-Acidity v-Flash point vi-Pour Point Note 2: Following shall be observed in visual inspection i-Tank body ii-Tubes iii-Oil level indicator iv-Bushings v-Paint and any other physical defect / shortcoming. Test As Specified in Scope of Work. The reclaimed transformers shall be inspected according to the specification mentioned here-under for stage as well as final testing:- a) Wapda Standard Specification No.DDS-84:2007 for distribution T/Fs with amendment No.4 excluding all type tests. b) WAPDA specification No.P-13-69 for Distribution Transformers excluding all types test. c) WAPDA specification No.P-72-70 for Bushing Rod connectors etc. d) IEC-296 for new transformer oil. e) ASTMD1170-62 STMDE-107-79 (a) for various Neoprene Rubber & Cork gas kits. f) BSS-3255-1955 press pan paper. g) DIN-7733 PSP -3052 Press Board Sheet Press Board Block. h) BSS-4516 part –IP 1969 for Enameled Copper Wire. i) BSS-4653 Part-II 1970 for LT Paper Covered Copper Strip. j) IEC-233-1974 for 11 KV Porcelain Bushing. k) IEC-233-1974 for LT Porcelain Bushing. l) Resin for transformer top cover for age long adherence and 8 KV di-electric with stand. m) All HT and LT Bushing to be filled w o) Oil level indication glass shall be 100 % replaced. p) Interior of transformer shall be painted with Red, Oxide of M/S Dulux, Berger or Buxly. q) Exterior of Transformer shall be spray painted in Grey with enamel paint of M/s Dulux, Berger or Buxly, 4 tubes shall be orange painted in addition to “RECLAIMED KVA” in bold stencil in orange colour, on transformers body. r) Reclaimed transformers shall be fitted with rating plate giving following information:- i- Reclamation workshop name ii- Work Order No. iii- Date of repair iv- Transformer capacity, Transformer serial number the word "LESCO" Inspection and Rejection:  The Inspecting Officer may reject a part or the whole of the consignment tendered for inspection, if after inspection such portion thereof as he may decide on his discretion he is satisfied that the consignment is below the requirements of the particulars governing the supply given in the work order.  The decision of the Inspecting Officer shall be binding on you.  If the stores are rejected as aforesaid, then without prejudice to the right of the purchaser: You may submit stores after re-repairing of those rejected but re-submission will not mean extension of delivery period. D) On final rejection the consignee shall have the following rights:- a) To get repaired the rejected goods at your cost and expense. b) To terminate the contract and recover from you the loss to LESCO thereby Delivery & Documents Payment will be made by the Chief Financial Officer, LESCO Lahore , out of budget from maintenance head on production of the following : i. Contractor’s bill in triplicate through Chief Engineer (MM) LESCO office for 90% payment duly supported by: ii. Delivery challan and GRN duly stamped and signed by the Regional Store Manager, LESCO Shalamar Lahore, WalgonSohail&Pattoki. iii. Warranty certificate as prescribed in Clause-5. iv. Confirmation of Chief Engineer (MM) LESCO about receipt/ accepta v. Inspection certificate issued by the designated inspection team / committee. vi. Copy of Store Requisition (SRs) vide which Repairable / Irrepairable T/Fs were handed over to contractor. vii. Payment for the contractor’s bill, for the balance 10% will be made by the CFO LESCO Lahore after 90-days of receipt of bills through Chief Engineer (MM) LESCO office duly supported by the consignee’s certificate of satisfactory operation after obtaining field performance from the end user viii. As per directions of FBR dated. 3.9.2015 conveyed vide C.E (Operation) PEPCO vide letter No. 1918-28 dated. 17.09.2015, the payment to the registered persons may be linked with the active taxpayer status of the suppliers as per FBR database. If any registered supplier is not in ATL his payment should be stopped till he files his mandatory returns and appears on ATL of FBR. Sales Tax invoice inscribing LESCO’s NTN No.3041097-7 & GST No. 03-05-2716-002-91 shall be provided at the time of delivery of equipment/material, even if zero-rated supply as per section 23 of the Act. The payment of sales tax shall be made as per Govt. of Pakistan at the time prevailing sales tax rate at the time of supply (presently 18%) on production of affidavit stating that sales tax has been paid through monthly sales tax return to the respective Collectorate of Sales Tax BILLS. Bills submitted by supplier duly completed in all respects, will be either passed for payment or rejected by competent authority within 15 days of the date of submission. Objection on the rejected bills shall be raised only once and not in piece meal. PARTIAL DELIVERIES AND PART PAYMENT ARE ALLOWED
GCC 31	Following is the guidance for Dispute Resolution If any dispute of any kind whatsoever shall arise between the Authority and the Bidder in connection with or arising out of the Contract, including without prejudice to the generality of foregoing, any question regarding its existence, validity, termination and the execution of the Contract – whether during developing phase or after their completion and whether before or after the termination, abandonment or breach of the Contract – the parties shall seek to resolve any such dispute or difference by mutual diligent negotiations in good faith within 14 (fourteen) days following a notice sent by one Party to the other Party in this regard. At future of negotiation the dispute shall be resolved through mediation and mediator shall be appointed with the mutual consent of the both parties. At the event of failure of mediation to resolve the dispute relating to this contract such dispute shall finally be resolved through binding Arbitration by sole arbitrator in accordance with Arbitration Act 1940. The arbitrator shall be appointed by mutual consent of the both parties. The Arbitration shall take place in Islamabad, Pakistan and proceedings will be conducted in English language. The cost of the mediation and arbitration shall be shared by the parties in equal proportion however the both parties shall bear their own costs and lawyer’s fees regarding their own participation in the mediation and arbitration. However, the Arbitrator may make an award of costs upon the conclusion of the arbitration making any party to the dispute liable to pay the costs of another party to the dispute. Arbitration proceedings as mentioned in the above clause regarding resolution of disputes may be commenced prior to, during or after completion of the contract. Notwithstanding any reference to the arbitration herein, the parties shall continue to perform their respective obligations under the Contract unless they otherwise agree that the Authority shall pay the Bidder any monies due to the Bidder. Arbitrator’s fee: The fee shall be specified in Pak Rupees, as determined by the Arbitrator, which shall be shared equally by both parties. Appointing Authority for Arbitrator: By the Mutual Consent or in accordance with the provisions of Arbitration Act, 1940, in case the parties fail to reach a consensus on the name of sole arbitrator, any party may submit an application to the Chief Justice Islamabad High Court for appointment of sole arbitrator. The Chief Justice IHC may appoint a former judge of any High Court or Supreme Court as the sole arbitrator to resolve the dispute between the parties. Rules of procedure for arbitration proceedings: Any dispute between the Authority and a Bidder who is a national of the Islamic Republic of Pakistan arising in connection with the present Contract shall be referred to adjudication or arbitration in accordance with the laws of the Islamic Republic of Pakistan including Arbitration Act 1940, however above provision shall prevail in referring the case to the Arbitrator. Place of Arbitration and Award: The arbitration shall be conducted in English language and place of arbitration shall be at Islamabad. The award of the arbitrator shall be final and shall be binding on the parties.

📑 Bid Securing Declaration (BSD)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Published on: Thursday, March 19, 2026

Ref# : P13409

Form 9: Bid Securing Declaration

Date: [insert date (as day, month and year)]

Bid No.:P13409

To: Material Management (Lahore Electricity Supply Company (LESCO)), Assistant Manager Procurement LESCO Head Quarter, 22-A, Queens Road., Lahore City, Lahore (District), Lahore Division (Division), Punjab (Province).

We, the undersigned, declare that:

We understand that, according to your conditions, Bids must be supported by a Bid Securing Declaration.

We accept that we will be blacklisted and henceforth cross debarred for participating in respective category of public procurement proceedings for a period of (not more than) six months, if fail to abide with a bid securing declaration, however without indulging in corrupt and fraudulent practices, if we are in breach of our obligation(s) under the Bid conditions, because we:

have withdrawn or modified our Bid during the period of Bid Validity specified in the Form of Bid;
Disagreement to arithmetical correction made to the Bid price; or
having been notified of the acceptance of our Bid by the Procuring Agency during the period of Bid Validity, (i) failure to sign the contract if required by Procuring Agency to do so or (ii) fail or refuse to furnish the Performance Security or to comply with any other condition precedent to signing the contract specified in the Bidding Documents.

We understand this Bid Securing Declaration shall expire if we are not the successful

Bidder, upon the earlier of (i) our receipt of your notification to us of the name of the successful Bidder; or (ii) twenty-eight (28) days after the expiration of our Bid.

📑 Contract Form (CNF)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Published on: Thursday, March 19, 2026

Ref# : P13409

SECTION IX: CONTRACT FORMS

THIS AGREEMENT made the _____ day of __________ 20_____ between Material Management (Lahore Electricity Supply Company (LESCO)), Assistant Manager Procurement LESCO Head Quarter, 22-A, Queens Road., Lahore City, Lahore (District), Lahore Division (Division), Punjab (Province).

(hereinafter called “the Procuring Agency”) of the one part and [name of Bidder] of [city and country of Bidder] (hereinafter called “the Bidder”) of the other part:

WHEREAS the Procuring Agency invited Bids for provision of goods, viz., TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers ) (P13409) and has accepted a Bids by the Bidder for the provision of Goods in the sum of [contract price in words and figures] (hereinafter called “the Contract Price”).

NOW THIS CONTRACT WITNESSETH AS FOLLOWS:

1. In this Contract words and expressions shall have the same meanings as are respectively assigned to them in the Conditions of Contract referred to.

2. The following documents shall be deemed to form and be read and construed as part of this Contract, In the event of any ambiguity or conflict between the Contract Documents listed below, the order of precedence shall be the order in which the Contract Documents are listed below:-

This form of Contract;
the Form of Bids and the Price Schedule submitted by the Bidder;
the Schedule of Requirements;
the Technical Specifications;
the Special Conditions of Contract;
the General Conditions of the Contract;
the Procuring Agency’s Letter of Acceptance; and
[add here: any other documents]

3. In consideration of the payments to be made by the Procuring Agency to the Bidder as hereinafter mentioned, the Bidder hereby covenants with the Procuring Agency to provide the Goods related services and to remedy defects therein in conformity in all respects with the provisions of the Contract.

4. The Procuring Agency hereby covenants to pay the Bidder in consideration of the provision of Goods and the remedying of defects therein, the Contract Price or such other sum as may become payable under the provisions of the contract at the times and in the manner prescribed by the contract.

IN WITNESS whereof the parties hereto have caused this Contract to be executed in accordance with their respective laws the day and year first above written.

Signed, sealed, delivered by __________________the ________________ (for the Procuring Agency)

Witness to the signatures of the Procuring Agency:

………………………………………………

Signed, sealed, delivered by __________________the ________________ (for the Procuring Agency)

Witness to the signatures of the Bidder: …………………………………………………

📑 Integrity Pact (INP)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Published on: Thursday, March 19, 2026

Ref# : P13409

Integrity Pact

DECLARATION OF FEES, COMMISSION AND BROKERAGE ETC. PAYABLE BYTHE SUPPLIERS OF GOODS, SERVICES & WORKS IN CONTRACTS WORTH RS.10.00 MILLION OR MORE

Contract Number: Contract Value: Contract Title:

Dated:

[Name of Supplier] hereby declares that it has not obtained or induced the procurement of any contract, right, interest, privilege or other obligation or benefit from Government of Pakistan or any administrative subdivision or agency thereof or any other entity owned or controlled by it (GoP) through any corrupt business practice.

Without limiting the generality of the foregoing [Name of Supplier] represents and warrants that it has fully declared the brokerage, commission, fee etc. paid or payable to anyone and not given or agreed to give and shall not give or agree to give to anyone within or outside Pakistan either directly or indirectly through any natural or juridical person, including its affiliate, agent, associate, broker, consultant, director, promoter, shareholder, sponsor or subsidiary, any commission, gratification, bribe, finder's fee or kickback, whether described as consultations fee or otherwise, with the object of obtaining or inducing the procurement of a contract, right, interest, privilege or other obligation or benefit in whatsoever form from GoP, except that which has been expressly declared pursuant hereto.

[Name of Supplier] certifies that it has made and will make full disclosure of all agreements and arrangements with all persons in respect of or related to the transaction with GoP and has not taken any action or will not take any action to circumvent the above declaration, representative or warranty.

[Name of Supplier] accepts full responsibility and strict liability for making and false declaration, not making full disclosure, misrepresenting fact or taking any action likely to defeat the purpose of this declaration, representation and warranty. It agrees that any contract, right interest, privilege or other obligation or benefit obtained or procured as aforesaid shall, without prejudice to any other right and remedies available to GoP under any law, contract or other instrument, be voidable at the option of GoP.

Notwithstanding any rights and remedies exercised by GoP in this regard, [Name of Supplier] agrees to indemnify GoP for any loss or damage incurred by it on account of its corrupt business practices and further pay compensation to GoP in an amount equivalent to ten time the sum of any commission, gratification, bribe, finder's fee or kickback given by [Name of Supplier] as aforesaid for the purpose of obtaining or inducing the procurement of any contract, right, interest, privilege or other obligation or benefit in whatsoever form from GoP.

📑 Performance Guarantee Form (PGF)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Published on: Thursday, March 19, 2026

Ref# : P13409

Performance Guarantee Form

WHEREAS [name of Bidder] (hereinafter called “the Bidder”) has undertaken, in pursuance of Contract No. [reference number of the contract] dated [insert date] for provision of Goods(hereinafter called “the Contract”).

AND WHEREAS it has been stipulated by you in the said Contract that the Bidder shall furnish you with a Bank Guarantee by a reputable bank for the sum specified therein as security for compliance with the Bidder’s performance obligations in accordance with the Contract.

AND WHEREAS we have agreed to give the Bidders guarantee:

THEREFORE, WE hereby affirm that we are Guarantors and responsible to you, on behalf of the Bidder, up to a total of [amount of the guarantee in words and figures], and we undertake to pay you, upon your first written demand declaring the Bidder to be in default under the Contract and without cavil or argument, any sum or sums within the limits of [amount of guarantee] as aforesaid, without your needing to prove or to show grounds or reasons for your demand or the sum specified therein.

This guarantee is valid until the: [insert date]

Signature and seal of the Guarantors

_____________________________________________________________________

[name of bank or financial institution]

_____________________________________________________________________

[address]

_____________________________________________________________________

[date}

📑 Annexure (ANX)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Published on: Thursday, March 19, 2026

Ref# : P13409

Submission of Duly Filled Annexures/Forms and Compliance with Tender Requirements

In continuation of the procurement process, it is requested that the attached forms/annexures may kindly be reviewed, duly filled, signed (where required), and re-attached/submitted accordingly. The information provided in these annexures shall form an integral part of the subject procurement/tender.

It is further clarified that all attached details and requirements, including but not limited to Bank Guarantee format/requirements, item specifications, mandatory clauses, technical parameters, and other relevant conditions, shall be considered binding and integral parts of the bidding documents for this procurement/tender. Therefore, the same must be carefully completed and submitted to ensure completeness of the procurement documentation.

Any missing or incomplete information shall be construed, interpreted, or derived from the relevant attached annexures/forms, and the same shall be treated as part of the bid for evaluation purposes. This includes, but is not limited to, Performance Guarantee requirements, testing/inspection criteria, payment terms, delivery schedule, and other contractual obligations, as specified in the annexures

Upload Technical Document

Document Required

📑 Procurement Forms (PFD)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Published on: Thursday, March 19, 2026

Ref# : P13409

Past Experience and Completed Contracts

The bidder should have atleast 02-years’ experience of manufacturing/repairing of Tranformers of the same nature or higher capacity. Supply record duly signed and stamped shall be provided with the bid otherwise bid will be considered as non-responsive. Atleast 2 Nos. of Purchase Orders along-with copy of GRN must be attached.

Standard Bidding Document

📑 Procurement Notice (NIT)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Ref# : P13409

PROCUREMENT OF NON-CONSULTANCY SERVICES

📑 Instructions to Bidders (ITB)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Ref# : P13409

A. Introduction

B. Bidding Documents

C. Preparation of Bids

D. Submission of Bids

E. Opening and Evaluation of Bids

F. Award of Contract

G. Grievance Redressal & Complaint Review Mechanism

H. Blacklisting/ Debarment

📑 Bid Data Sheet (BDS)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Ref# : P13409

Bids Data Sheet (BDS)

A. Introduction

B. Bidding Documents

C. Preparation of Bids

D. Submission of Bids

E. Opening and Evaluation of Bids

F. Award of Contract

G. Review of Procurement Decisions

Eligibility Criteria

Evaluation Criteria

Required Services

Related Services :

Services Specifications

Scope of Work

DELIVERY PERIOD:

Price Schedule

📑 General Conditions of Contract (GCC)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Ref# : P13409

A. General

B. Commencement, Completion, Modification, and Termination of Contract

C. Obligations of the Contractor

D. Contractor’s Personnel

E. Obligations of the Procuring Agency

F. Payments to the Contractor

📑 Special Conditions of Contract (SCC)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Ref# : P13409

SECTION VIII. SPECIAL CONDITIONS OF CONTRACT

Inspections & Tests Requirements

Delivery & Documents

📑 Bid Securing Declaration (BSD)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Ref# : P13409

Form 9: Bid Securing Declaration

📑 Contract Form (CNF)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Ref# : P13409

SECTION IX: CONTRACT FORMS

📑 Integrity Pact (INP)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Ref# : P13409

Integrity Pact

DECLARATION OF FEES, COMMISSION AND BROKERAGE ETC. PAYABLE BYTHE SUPPLIERS OF GOODS, SERVICES & WORKS IN CONTRACTS WORTH RS.10.00 MILLION OR MORE

📑 Performance Guarantee Form (PGF)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Ref# : P13409

Performance Guarantee Form

📑 Annexure (ANX)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Ref# : P13409

Submission of Duly Filled Annexures/Forms and Compliance with Tender Requirements

📑 Procurement Forms (PFD)

TENDER NO 4332 (Reclamation of 200-KVA Repairable & Irrepairable Distribution Transformers )

Ref# : P13409

Past Experience and Completed Contracts